HomeMy WebLinkAboutR28-Economic Development
CITY OF SAN BERNARDINO
ECONOMIC DEVELOPMENT AGENCY
r~ l
e....". ~
I \ I
/'"
l ~1
~4
\ I 1"\ !
; '.; ~ I
, \1 ~.~
I \it \ L,,,
FROM:
Emil A. Marzullo
Interim Executive Director
SUBJECT:
Award of a Construction Contract in the
amount of $46,048.50 for Walls Support -
California Theatre of the Performing Arts
located at 562 West 4th Street (Central City
North Redevelopment Project Area)
DATE:
October 15,2008
SvnoDsis of Previous Commission/Council/Committee Action(s):
On September 18, 2008, Redevelopment Committee Members Estrada, Johnson and Baxter unanimously voted to recommend
that the Community Development Commission consider this action for approvaL
Recommended Motion(s):
(Communitv Develooment Commission)
Resolution of the Community Development Commission of the City of San Bernardino approving and
authorizing the Interim Executive Director of the Redevelopment Agency of the City of San Bernardino
("Agency") to execute a Construction Contract by and between the Agency and Francisco Construction (the
"Contractor") for wall structural support system ("Improvements") to the California Theatre of the Performing
Arts (Central City North Redevelopment Project Area)
Contact Person(s): Carey K. Jenkins Phone:
(909) 663-1044
Project Area(s):
Supporting Data Attached:
Central City North
Redevelopment Project Area
Ward(s):
1>'1 Staff Report "'" Resolution(s)"", Agreement(s)/Contract(s) 0 Map(s) 0 Letter(s)
FUNDING REQUIREMENTS:
Amount: $ 46,048.50
Source:
Tax Increment
Budget Authority:
2008-2009 Budget
Signature &. ~ .e~- ~l
Emil A. Marzullo, Interim Ex utive Director
Fiscal Review:
"J
[)u
Barbara Un
CG<- t:{
Commission/Council Notes:
---.-nK;:;;';; nmnC;J'fi/ioop.0<'/nn.--n-nmnm
[\Documents and Settingslwchamha\Local Selling~\Temporary Int....rnel Files\OLKF4\IO-20-08 Francisco Construction CA Thealre Wall Suppon Contract SR Ojdoc COMMISSION
MEETING AGENDA
Meeting Date: 10/20/2008
Agenda Item Number: fl.~
IO"'UJ~08
ECONOMIC DEVELOPMENT AGENCY
ST AFF REPORT
A WARD OF A CONSTRUCTION CONTRACT IN THE AMOUNT OF $46,048.50
FOR WALLS SUPPORT - CALIFORNIA THEATRE OF THE PERFORMING ARTS
LOCATED AT 562 WEST 4TH STREET
(CENTRAL CITY NORTH REDEVELOPMENT PROJECT AREA)
BACKGROUND:
On July 17, 2008, the City of San Bernardino Economic Development Agency (the "Agency") executed a
purchase order with a licensed structural engineer to design a support system for the wall directly above
the main entrance doors of the California Theatre of the Performing Arts (the "Theatre") located at 562
West 4th Street in San Bernardino, California. The Theatre which has been owned, operated and
maintained by the Agency since 1994, serves as a downtown icon as well as a regional cultural and
entertainment center.
The need for such a design resulted from what appears to be gradual sagging of the wall support that
caused three of the eight entrance doors to compress making it difficult to open and close them without
constant re-adjustment (the "Project"). Originally, the estimated cost to complete the Project was
projected to be under $25,000. As a result, Agency Staff procured construction services for the Project
through a standard purchase order format. This entailed soliciting five separate bids from general
contractors. In this case, Agency Staff utilized the active list of general contractors approved by
Neighborhood Housing Services of the Inland Empire CNHSIE") for their Homeowner Beautification
Grant and Loan Programs. Bid packages were issued and followed by a confirming phone call to each
potential bidder. On August 21, 2008, a job walk was conducted at the Theatre. There were three
potential bidders who participated.
Final bids were due on August 28, 2008 and the Agency received two bids which were deemed to be
responsive. However, both bids were in excess of the $25,000 threshold thus preventing a standard
purchase order format from being considered.
CURRENT ISSUE:
Based on the stated price for each bid, the lowest qualified and responsible bidder was Francisco
Construction Company (the "Contractor"), in the amount stated below:
Company
Francisco Construction Company
AFM Construction
Bid Amount
$41,862.50
$45,200.00
In reviewing the Agency's procurement policies, other than not advertising the bid in at least one
newspaper of general circulation, the Agency generally followed appropriate procurement procedures
consistent with the contract bid amounts that were submitted. This included sending the appropriate bid
package to a general list of Agency vendors for consideration, followed by a job walk of the Project site
and a request for sealed bids.
C \Documents and SeltingslwchanlhalLocal Senings\Temporary Imemel Files\OLKF4\IO-20-08 Frallci,co Constructio" - C A Theatre Wall Support ConTract SR 0) doc
COMMISSION
MEETING AGENDA
Meeting Date: 10/20/2008
Agenda Item Number:
Economic Development Agency Staff Report
Francisco Construction - CA Theatre Wall Support
Page 2
Though the number of responses were below the standard of three as suggested in the procurement policy,
it can be argued that limited competition is permissible when: I) an emergency exists which requires
immediate attention because of the possibility of injury, loss of life, destruction of property, or missed
opportunity; or 2) there is a matter impinging on health or safety.
In this case, a clear line can be drawn between the needed repairs to the wall support in order to avert
injury or further damage/destruction of the property. As a result, Agency Staff recommends entering into
a construction contract with the Contractor despite not having initially advertised the bid notice in a
newspaper of general circulation.
Based on the Contractor's bid, the work required to make the necessary repairs should take approximately
12 weeks once an agreement has been executed with the Agency. Agency Staff has spoken to
representatives of the Contractor and verified that all insurance and bonding requirements are presently
available and up-to-date and will be verified as a part of the Agency's standard contract execution
process.
ENVIRONMENTAL IMP ACT:
This action does not constitute a Project under the California Environmental Quality Act CCEQA").
FISCAL IMP ACT:
A total of $46,048.50 is budgeted for the improvements ($41,862.50, plus a 10% contingency of
$4,186.00) from the Central City North Redevelopment Project Area Tax Increment.
RECOMMENDATION:
That the Community Development Commission adopt the attached Resolution.
~
Emil A. Marzullo, Int
C\Documents and Senings\wchantha\Local SeningslTemporary Internet FilesIOLKF4\lO-20-08 Francisco Consln,ction - CA Theatre ',\,'all Suppon Contract SR (3) doc COMMISSION
MEETING AGENDA
Meeting Date: 10/20/2008
Agenda Item Number:
1
RESOLUTION NO.
CC (Q) [Pl(
2
7
RESO! lJTION OF THE COMMUNITY DEVELOPMENT COMMISSION
OF THE CITY OF SAN BERNARDINO APPROVING AND
AUTHORIZING THE INTERIM EXECUTIVE DIRECTOR OF THE
REDEVELOPMENT AGENCY OF THE CITY OF SAN BERNARDINO
("AGENCY") TO EXECUTE A CONSTRUCTION CONTRACT BY AND
BETWEEN THE AGENCY AND FRANCISCO CONSTRUCTION
COMPANY FOR IMPROVEMENTS TO THE CALIFORNIA THEATRE
OF THE PERFORMING ARTS (CENTRAL CITY NORTH
REDEVELOPMENT PROJECT AREA)
3
4
5
6
8
9 WHEREAS, the Redevelopment Agency of the City of San Bernardino (the "Agency") is a
10 community redevelopment agency duly created, established and authorized to transact business and
11 exercise its powers, all under and pursuant to the California Community Redevelopment Law (the
12 "CRL"), codified under Division 24, Part I of the California Health and Safety Code commencing at
13 Section 33000; and
14 WHEREAS, the Agency owns the California Theatre of the Performing Arts (the "Theatre")
15 and the Agency desires the front entrance doors of the Theatre to be repaired in accordance with the
16 plans and specifications ("Improvements") as approved by the City of San Bernardino Building and
17 Safety Division; and
18 WHEREAS, on August 14, 2008, construction bids were solicited from an active list of
19 general contractors approved by the Neighborhood Housing Services of the Inland Empire for their
20 Agency sponsored Neighborhood Beautification Program; and
21 WHEREAS, ajob walk was conducted on August 21, 2008, at the Theatre that was attended
22 by three potential bidders; and
23 WHEREAS, on August 28, 2008, responses were received by the Agency wherein Francisco
24 Construction Company (the "Contractor") was determined to be the most qualified, responsive and
25 cost effective bidder; and
26 WHEREAS, the Agency desires to retain the services of the Contractor to repair the front
27 entrance doors of the Theatre, the terms and conditions of which are in accordance with the Contract
28 attached hereto and incorporated herein by this reference (the "Contract").
I
P 'Agendas\Resolutions",Resolulions\2008'oI0-20- 08 Francisco COllsln,Jction - CA Thealre Wall Support CDC Reso,dDc
I WHEREAS, the Improvements to be constructed pursuant to the Contract are categorically
2 exempt per Article 19, Section 15302, Class 2 of the California Environment Quality Act'
3 ("CEQA").
4 NOW, THEREFORE, THE COMMUNITY DEVELOPMENT COMMISSION OF THE
5 CITY OF SAN BERNARDINO DOES HEREBY RESOLVE, DETERMINE AND ORDER, AS
6 FOLLOWS:
7
Section I.
The Community Development Commission of the City of San Bernardino
8 ("Commission") hereby approves the Contract between the Agency and the Contractor attached
9 , hereto and incorporated herein by reference and hereby authorizes the Agency Interim Executive
10 Director to execute the Contract on behalf of the Agency together with such technical and
II conforming changes as may be recommended by the Interim Executive Director of the Agency and
12 approved by the Agency Counsel.
13
Section 2.
The Commission finds that the Improvements to be constructed under the
14 scope ofthe Contract are categorically exempt pursuant to CEQA
This Resolution shall take effect from and after its date of adoption by this
15 Section 3,
I
16 Commission.
17 /1/
18 /II
19 /II
20 /II
21 /II
22 //1
23 /1/
24 /II
25 /1/
26 /II
27 //1
28 /II
2
P \Agenda5\Resolulions\Resolutions\2008\IO~20- 08 Francis~" oruelion. CA Theatre VlrAII Sl,lpport CDC Reso doc
1
2
RESOLUTION OF THE COMMUNITY DEVELOPMENT COMMISSION
OF THE CITY OF SAN BERNARDINO APPROVING AND
AUTHORIZING THE INTERIM EXECUTIVE DIRECTOR OF THE
REDEVELOPMENT AGENCY OF THE CITY OF SAN BERNARDINO
("AGENCY") TO EXECUTE A CONSTRUCTION CONTRACT BY AND
BETWEEN THE AGENCY AND FRANCISCO CONSTRUCTION
COMPANY FOR IMPROVEMENTS TO THE CALIFORNIA THEATRE
OF THE PERFORMING ARTS (CENTRAL CITY NORTH
REDEVELOPMENT PROJECT AREA)
3
4
5
6
7
I HEREBY CERTIFY that the foregoing Resolution was duly adopted by the Community
8 Development Commission of the City of San Bernardino at a
, 2008, by the following vote to wit:
meeting
Navs
Abstain
Absent
19
Secretary
20 The foregoing Resolution is hereby approved this
,2008.
day of
21
22
Patrick J. Morris, Chairperson
Community Development Commission
of the City of San Bernardino
23
24
Approved as to Form:
25
26BYl~J
27 V"Agenc ~~l
28
I
II r 'A,md"IR"01""",',,01''',,,,'2008\10-20- O. ,,,,,i,ro Coo"ru"'oo - CA Th"", W,II s~po, CDC .,,, do,
PROJECT CONTRACT
REDEVELOPMENT AGENCY OF THE CITY OF SAN BERNARDINO
CALIFORNIA THEATRE PROJECT - 562 WEST 4TH STREET, SAN BERNARDINO
THIS PUBLIC WORKS PROJECT CONTRACT for the wall structural supports system above
the front doors for the City of San Bernardino California Theatre of the Performing Arts project (the
"Contract"), is made and entered into this 20th day of October, 2008, by and between Redevelopment
Agency of the City of San Bernardino (referred to herein as the "Owner" or the "Agency") and
Francisco Construction (the "Contractor").
IN WITNESS HEREOF, THE UNDERSIGNED PARTIES HAVE MUTUALLY AGREED
TO THE FOLLOWING:
1. THE CONTRACT DOCUMENTS. The complete contract is comprised of and includes: I)
the Instructions to Bidders; 2) this Contract; 3) Contractor'slBidder's Bid, 4) Contractor'slBidder's
Statement of Experience; 5) Contractor'slBidder's Certification Concerning Clean Air and Water
Pollution Control; 6) Contractor'slBidder's Certification Concerning Designation of Subcontractors; 7)
Non-Collusion Affidavit; 8) Contractor'slBidder's Certification Relating to Campaign Contributions;
9) Contractor'slBidder's Certification Concerning Worker's Compensation Insurance; 10) Certification
of Insurance Coverage; 1 I) Copies of State of California Contractor's Licenses, City of San
Bernardino Business License, Worker's Compensation Insurance, Comprehensive General Liability
Insurance per Contract; 12) Form of Labor & Material Bond; 13) the complete Project Construction
Plans and Specifications and Provisions; 14) General Conditions (including without limitation, Part I,
Sections 1-9 of "Standard Specifications for public Works Construction, 2000 editorial (the
"Greenbook") as supplemented by the 2002 "Cumulative Supplement to Greenbook"); 15) any
Addenda issued under the Instructions to Bidders; I 6) Any Regulations, Ordinances, Codes, and Laws
incorporated therein or herein by reference or otherwise applicable to the Project; I 7) Any Agency
approved Change Order( s) submitted during construction.
All of the above documents are intended to cooperate as one (I) contract so that any work called for in
one (I) and not mentioned in the other, or vice versa, is to be executed the same as if mentioned in all
said documents. The documents comprising the complete contract are hereinafter referred to
collectively as the "Contract Documents".
2. THE WORK. Contractor agrees to furnish all tools, apparatus, facilities, equipment, labor and
materials (except that specifically mentioned as being furnished by others) necessary to perform and
complete the work in a good and worker like manner as called for, and in the manner designated in,
and in strict conformity with the Project Construction Plans, Detail Specifications, and other Contract
Documents which are identified by the signatures of the parties to this Contract and are, collectively,
entitled:
REDEVELOPMENT AGENCY OF THE CITY SAN BERNARDINO
CALIFORNIA THEATRE PROJECT - 562 WEST 4TH STREET, SAN BERNARDINO
3. CONTRACT PRICE. The Agency agrees to pay and the Contractor agrees to accept, in full
payment for the work above agreed to be done, the following compensation, to-wit: Amounts as
I
determined by applying the information contained in the Contractor's bid for the 'wall structural
support system above the front doors for the California Theatre' (the "Project"). The amount of this
Contract for the Project is Forty One Thousand Eight Hundred Sixty Two Dollars and 50/100
($41,862.50).
4. CONTRACT AMENDMENTS. The Interim Executive Director of the Agency is authorized
to sign on his or her own authority amendments to this Contract which are of routine or technical
nature, including minor adjustments to the Schedule of Performance unless otherwise specified in this
Contract. All other amendments require the mutual agreement of both the Agency and the Contractor.
5. INCORPORATION BY REFERENCE OF PART I, SECTIONS 1-9 OF THE GREENBOOK,
2000 EDITION, AS SUPPLEMENTED. The Greenbook, as supplemented by the publication
entitled, "2002 Cumulative Supplement to Greenbook", is hereby incorporated by this reference into
this Contract.
The word "Project" means and refers to the "Project", as this term is defined in the Instruction to
Bidders.
To the extent that any provision of the printed text which appears in this Contract, is in conflict with
the printed text of the provisions of the Greenbook as incorporated into this Contract by this reference,
then in such event, the printed text of this Contract shall take precedence over such printed text in the
Greenbook.
6. PAYMENT. Not later than the 20th day of each calendar month, the Contractor shall make a
partial payment request to the Agency on the basis of an estimate approved by the Architect and
Agency of the work performed since the last partial payment request during the preceding month by
the Contractor with (10%) ten percent of the amount of each such estimate retained by the Agency,
until completion of the Project and the recordation of a Notice of Completion of all work covered by
this Contract. The Agency shall make any partial payments provided for in this contract to the
Contractor within thirty (30) calendar days of the Agency's receipt of an undisputed and properly
executed partial payment request from the Contractor.
The Agency shall pay the Contractor interest on the amount of any portion of a partial payment,
excluding retention amounts, not made to the Contractor within thirty (30) calendar days of the
Agency's receipt of an undisputed and properly executed partial payment request from the Contractor
at the legal rate set forth in California Code of Civil Procedure Section 685.010. Upon receipt of a
partial payment request from the Contractor, the Agency shall review the partial payment request for
the purpose of determining whether or not the partial payment request is a proper partial payment
request. Any partial payment request determined by the Agency not to be a proper partial payment
request suitable for payment shall be returned to the Contractor by the Agency within ten (10) working
days of the Agency's receipt of such partial payment request. A partial payment request returned to
the Contractor by the Agency under the provisions of this section shall be accompanied by a written
document setting forth the reason(s) why the partial payment request is not proper. The number of
days for the Agency to make a certain partial payment provided for in this Contract, without incurring
interest pursuant to this section, shall be reduced by the number of days by which the Agency exceeds
the ten (10) working days return period for such partial payment request, if determined to be improper,
as set forth in this section. For the purposes of this section, a "partial payment" means all payments
due to the Contractor under this contract, exclusive of that portion of the final payment designated as
retention earnings. Also, for the purposes of this section, a partial payment request shall be considered
2
properly executed by the Agency, if funds are available to pay the partial payment request and
payment is not delayed due to an audit inquiry by the Agency's financial officer. The Agency will
release Contractor's reteniion earnings within forty-five (45) days after recordation of Notice of
Completion, as defined in California Civil Code Section 3093. Recordation ofa Notice of Completion
for the Project by the Agency shall constitute the Agency's acceptance of the Project work.
7. STOP NOTICE. Contractor shall promptly pay all valid bills and charges for material,
labor, equipment or otherwise in connection with or arising out of the performance of this Contract,
and will hold the Agency free and harmless against all liens and!or claims of lien for material, labor or
equipment filed against ihe Agency, and from and against all expenses and liability in connection
therewith, including, but not limited to, court costs and attorney's fees resulting or arising therefrom.
In the event any liens and/or claims of lien are filed for record against the Agency or any property
owned by the Agency, or the Agency receives notice of any unpaid bill or charge in connection with
the performance of this Contract, Contractor shall forthwiih either pay and discharge the liens and! or
claims of lien and cause same to be released of record, or Contractor shall furnish the Agency with
proper indemnity, either by satisfactory corporate Surety Bond or satisfactory title policy. Said
indemnity shall also be subject to approval of Lien Holder.
8. TIME FOR COMPLETION. All work under this Contract shall be completed within a period
of ninety (90) calendar days from the date of the Contractor's receipt of Notice to Proceed from ihe
Agency which date may first occur; provided, however, that the Contractor shall have received its
Notice to Proceed anticipated to be wiihin fourteen (14) calendar days.
9. EXTENSION OF TIME. Ifihe Contractor is delayed by acts of negligence ofihe Agency,
or its employees or those under it by Contract or oiherwise, or by changes ordered in ihe work, or by
strikes, lockouts, fire, unavoidable casualties, or any causes beyond the Contractor's control, or by
delay authorized by the Agency, or by any justifiable cause which ihe Architect and Agency shall
authorize, then the Contractor shall make out a written claim addressed to the Agency setting forth ihe
reason for the delay and ihe extension of the time requested and forward a copy of the claim to the
Architect and Agency for approval. The Architect and Agency will evaluate ihe claim and ifthe claim
is justifiable, will request the Agency's approval. No such extension will be allowed unless written
claim therefore has been made wiihin ihree (3) working days after the delay became apparent.
10. LIQUIDATED DAMAGES FOR DELAY. The provisions of Section 6.9 of the Greenbook
are hereby modified to provide for a liquidated damages amount of Two Hundred Dollars ($200) per
working day.
II. CHANGE ORDERS. No change in work, as described in ihe Contract Documents, shall be
made except upon the approval of the Agency. The Contractor shall not be entitled to any
compensation for any additional work unless such Project Change Order is written and entered into by
the Contractor and the Agency. The Project Change Order shall describe the nature of the additional
work in detail, the location of the work, the time for completion ihereof, and terms of compensation to
be paid to ihe Contractor for its performance in accordance with this Contract, as modified by the
Project Change Order.
12. REAL PROPERTY LIENS. The Contractor shall promptly pay all valid bills and charges for
material, labor or otherwise in connection wiih or arising out of ihe performance of this Contract, and
will hold the Agency free and harmless against all liens and/or claims of lien for material and labor
filed against the real property or any part thereof, and from and against all expense and liability in
3
connection therewith, including, but not limited to, court costs and attorney's fees resulting or arising
therefrom. In the event any liens and/or claims of lien are filed for record against the real property, or
the Agency receives notices of any unpaid bill or charge in connection with the performance of this
Contract, the Contractor shall forthwith either pay and discharge the liens and/or claims of lien and
cause same to be I~;eased ofrecord, or the Contractor shall furnish the Agency with proper indemnity,
either by satisfactory corporate surety bond or satisfactory title policy. Said indemnity shall also be
subject to approval of the lien holder.
13. INDEMNIFICA nONS AND HOLD HARMLESS. The Contractor shall defend,
indemnifY, protect and hold free and harmless the Agency, its officers, employees, and agents from
and against any and all actions, suits, proceedings, claims, demands, losses, costs, injuries to or death
of any person or persons and expenses, including attorney's including attorney's fees, for injury or
damage of any type claimed which is brought by any individual or entity, whether public or private, as
a result of the acts, errors or omissions of the Contractor, its officers, employees, agents, and its
Subcontractors arising from or related to performance of the work required hereunder to complete the
Project.
14. INSURANCE. The provisions of Section 7-3 and Section 7-4 of the Greenbook are
hereby amended to read as follows for the purposes of this Contract:
The Contractor shall procure and maintain insurance policies meeting the minimum requirements set
forth below. Insurance shall be provided by insurers satisfactory to the Agency. Certificates
evidencing insurance coverage shall be delivered to the Agency for each policy required herein prior to
commencement of any work. All insurance certificates shall name the Agency as an additional insured
and provide for thirty (30) days prior to written notice of cancellation to the Agency.
a. Comprehensive General Liabilitv Insurance. The Contractor shall maintain
comprehensive general liability insurance of not less the One Million Dollars ($1,000,000)
combined single limit per occurrence. The Contractor must provide Comprehensive General
Liability Insurance Policy with appropriate endorsement for builders course of construction and
fire casualty loss.
b. Automobile Insurance. The Contractor shall maintain comprehensive automobile
liability insurance of not less than One Million Dollars ($1,000,000) combined single limit per
occurrence.
c. Worker's Compensation. The Contractor shall maintain adequate Worker's
Compensation Insurance in accordance with Section 3700 of the California Labor Code for all
workers under it employ and any Subcontractors performing the work required herein, or
secure from the Director of Industrial Relations. a certification to self-insure such workers
. ,
when such workers comes within the protection of such Workers' Compensation Insurance
Laws.
15. LABOR PROVISIONS.
a. Prevailing Wages.
The Project is a "public work" as this term is defined under applicable State Law (See California
Labor Code Section 1720, et seq. and California Administrative Code, Title 8, Section 16000, et seq.).
4
(1) All laborers and mechanics employed or working upon the site of the Project will be
paid unconditionally and not less often than once a week, and without subsequent deduction or rebate
on any account the full amount of wages and bona fide fringe benefits (or cash equivalents thereof) due
at time of payment computed at rates not less than those contained in the wage determination of the
Director of the Department of Industrial Relations (the "Director") regardless of any contractual
relationship which may be alleged to exist between the Contractor and such laborers and mechanics.
Such laborers and mechanics shall be paid the appropriate wage rate and fringe benefits on the wage
determination for the classification of work actually performed, without regard to skill, except as
provided in paragraph d. of this Section 14. Laborers or mechanics performing work in more than one
(1) classification may be compensated at the rate specified for each classification for the time actually
worked therein, provided that the employer's payroll records accurately set forth the time spent in each
classification in which work is performed. The wage determination shall be posted at all times by the
Contractor and its Subcontractors at the site of the Project in a prominent and accessible place where it
can easily be seen by the workers.
(2) Whenever the minimum wage rate prescribed in the Contract for a class of laborers or
mechanics includes a fringe benefit which is not expressed as an hourly rate, the Contractor shall either
pay the benefit as stated in the wage determination or shall pay another bona fide fringe benefit or an
hourly cash equivalent thereof.
(3) If the Contractor does not make payments to a trustee or other third person, the
Contractor may consider as part of the wages of any laborer or mechanic, the amount of any costs
reasonably anticipated in providing bona fide fringe benefits under a plan or program, provided that the
Director has found, upon the written request of the Contractor, that the applicable standards of the
Prevailing Wage Law have been met. The Director may require the Contractor to set aside, in a
separate account, assets for the meeting of obligations under the plan or program.
b. Withholding. The Agency shall, upon its own action or upon written request of an
authorized representative of the Department of Industrial Relations, withhold or cause to be withheld
from the Contractor under this Contract or any other contract with the same Contractor, or any other
contract subject to prevailing wage requirements, which is held by the same Contractor, so much of the
accrued payments or advances as may be considered necessary to pay laborers and mechanics,
including apprentices, trainees, and helpers, employed by the Contractor or any subcontractor the full
amount of wages required by the contract. In the event of failure to pay any laborer or mechanic,
including any apprentice, trainee, or helper, employed or working on the site of the Project, all or part
of the wages required by the Contract, the Agency may after written notice to the Contractor, take such
action as may be necessary to cause the suspension of any further payment, advance, or guarantee of
funds until such violations have ceased.
c. Pavrolls and Basic Records.
(1) Payrolls and basic records relating thereto shall be maintained by the Contractor during
the course of the work and preserved for a period of three (3) years thereafter for all laborers and
mechanics working at the site of the Project. Such records shall contain the name, address, and social
security number of each such worker, his or her correct classification, hourly rates of wages paid, daily
and weekly number of hours worked, deductions made and actual wages paid. Whenever the Director
has found under paragraph (3) of this clause that the wages of any laborer or mechanic include the
amount of any costs reasonably anticipated in providing benefits under such plan or program, the
Contractor shall maintain records which show that the commitment to provide such benefits is
enforceable, that the plan or program is financially responsible, and that the plan or program has been
5
communicated in writing to the laborers or mechanics affected, and records which show the costs
anticipated or the actual costs incurred in providing such benefits. If the Contractor employs
apprentices or trainees under approved programs, the Contractor shall maintain written evidence of the
registration of apprenticeship programs and certification of trainee programs, the registration of the
apprentices and trainees, and the ratios and wage rates prescribed in the applicable programs.
(2) (i) The Contractor shall prepare weekly payrolls for each week in which any Contract
work is performed. The payrolls shall set out accurately and completely all of the information required
to be maintained under paragraph c.(I) above. This information may be prepared in any form desired.
The Contractor is responsible for obtaining copies of the payrolls by all Subcontractors.
(ii) Each payroll prepared shall be accompanied by a "Statement of Compliance,"
signed by the Contractor or Subcontractor or his or her agent who pays or supervises the payment of
the persons employed under the Contract and shall certify the following:
(A) That the payroll for the payroll period contains the information required to
be maintained under paragraph c. (I) above and that such information is correct and complete;
(8) That each laborer and mechanic (including each helper, apprentice and
trainee) employed on the contract during the payroll period has been paid the full weekly wages
earned, without rebate, either directly or indirectly, and that no deductions have been made either
directly or indirectly from the full wages earned, other than permissible deductions;
(C) That each laborer or mechanic has been paid not less than the applicable
wage rates and fringe benefits or cash equivalents for the classification of work performed, as specified
in the applicable wage determination incorporated into the Contract.
(iii) Whenever a Contractor or Subcontractor is found by the Labor Commissioner to
be in violation of the Prevailing Wage Law with intent to defraud, the Contractor or Subcontractor
shall be ineligible for a period of not less than one (I) year or more than three (3) years to bid or
perform work on a public works contract.
(3) The Contractor or Subcontractor shall make the records required under paragraph c.(I)
of this section available for inspection, copying or transcription by authorized representatives of the
Agency, any office of the Division of Labor Standards Enforcement or the Division of Apprenticeship
Standards, and shall permit such representatives to interview employees during working hours on the
job. If the Contractor or Subcontractor fails to submit the required records or to make them available,
the Labor Commissioner may, after written notice to the Contractor or the Agency, take such action as
may be necessary to cause the withholding of any further payment, advance, or guarantee of funds by
the Agency, and determination of a penalty as set forth in Labor Code Section 1775, et seq.
d. Apprentices and Trainees.
(I) Apprentices. Apprentices, as defined in Labor Code Section 3077, will be permitted to
work at less than the predetermined rate for the work they perform when they are in training under
apprenticeship standards that have been approved by the Chief of the Apprenticeship Standards and
who are parties to written apprentice agreements under Chapter 4 (commencing with Section 3070) of
Division 3 of the Labor Code. The allowable ratio of apprentices to journeymen on the Project site in
any craft classification shall not be greater than the ratio permitted to the Contractor as to the entire
6
work force under the rules and regulations of the California Apprenticeship Council. Any worker listed
on a payroll at an apprentice wage rate, who is not employed as stated above, shall be paid not less
than the applicable wage rate on the wage determination for the classification of work actually
performed. In addition, any apprentice performing work on the job site in excess of the ratio permitted
under the apprenticeship standards and agreements shall be paid not less than the applicable wage rate
on the wage determination of the work actually performed. Every apprentice must be paid at not less
than the rate specified in the apprenticeship agreement for the apprentice's level of progress, expressed
as a percentage of the journeymen hourly rate specified in the applicable wage determination.
Apprentices shall be paid fringe benefits in accordance with the provisions of the apprenticeship
program. If the apprenticeship program does not specify fringe benefits, apprentices must be paid the
full amount of fringe benefits listed on the wage determination for the applicable classification. If the
Administrator of Apprentices determines that a different practice prevails for the applicable apprentice
classification, fringes shall be paid in accordance with that determination
(2) Trainees. Trainees will not be permitted to work at less than the predetermined rate for
the work performed unless they are employed pursuant to and individually registered an "on-the-job
training" program established pursuant to Labor Code Section 3093. The ratio of trainees to
journeymen on the Project site shall not be greater than permitted under the program pursuant to
Section 3093 by the California Apprenticeship Council in cooperation with the Department of
Education, the Employment Development Department, and the Board of Governors of the California
Community Colleges. Every trainee must be paid at not less than the rate specified in the approved
program for the trainee's level of progress. Trainees shall be paid fringe benefits in accordance with
the provisions of the trainee program. If the trainee program does not mention fringe benefits, trainees
shall be paid the full amount of fringe benefits listed on the wage determination unless the
Administrator of Apprentices so determines. Any employee listed on the payroll at a trainee rate who
is not registered and participating in an "on-the-job training" program established pursuant to Section
3093 shall be paid not less than the applicable wage rate on the wage determination for the
classification of work actually performed. In addition, any trainee performing work on the Project site
in excess ofthe ratio permitted under the "on-the-job training" program as established shall be paid not
less than the applicable wage rate on the wage determination for the work actually performed. In the
event the Administrator of Apprentices withdraws approval of an "on-the-job training" program, the
Contractor will no longer be permitted to utilize trainees at less than the applicable predetermined rate
for the work performed until an acceptable program is approved.
(3) Equal Emplovment Opportunity. The utilization of apprentices, trainees and
journeymen under this part shall be in conformity with the prohibitory discrimination provisions of
California law as set forth in the California Constitution, Article I, Section 8, Government Code
Section 12900, et seq. and Labor Code Sections 1735, 1777.6 and 3093.
e. Subcontracts. The Contractor and each Subcontractor shall insert in any subcontracts
the clauses contained in paragraphs a. through i. of Section IS. of this Contract and such other clauses
as maybe required, and also a clause requiring the Subcontractors to include these clauses in any lower
tier subcontracts. The Contractor shall be responsible for the compliance by any Subcontractor or
lower tier Subcontractor with all the Contract clauses and all requirements of the Prevailing Wage
Law.
f. Contract Termination. A breach of the Contract clauses in paragraphs a. through i. of
this Section 15 and a. through e. of Section 16 below are grounds for termination of this Contract, and
for the withholding of payment by the Agency and notification to the Division of Labor Standards
Enforcement or the Division of Apprenticeship Standards, as applicable.
7
g. Compliance with Prevailing Wage Law and Related Regulatory Requirements. All
rulings and interpretations of the Prevailing Wage Law, and the related regulations promulgated
thereunder contained in Title 8 CCR Section 16000, et seq., are herein incorporated by reference in this
Contract.
h. Disputes Concerning Labor Standards. Disputes arising out of the labor standards
provisions of this Contract shall not be subject to the general disputes provision of this Contract. Such
disputes shall be resolved in accordance with the procedures of the Department of Industrial Relations
as set forth in Title 8 CCR section 16000, et seq. Disputes within the meaning of this clause include
disputes between the Contractor (or any of its Subcontractors) and the Agency, the Department of
Industrial Relations, or the employees or their representatives.
1. Certification of Eligibilitv.
(I) By entering into this Contract, the Contractor certifies that neither it (nor he or she) nor
is any person or firm who has an interest in the Contractor's firm a person or firm ineligible to be
awarded a public works contract by virtue of Labor Code Section 1775, et seq.
(2) No part of this contract shall be subcontracted to any person or firm ineligible for award
of a public works contract by virtue of Labor Code Section 1775, et seq.
16. CONTRACT WORK HOURS AND SAFETY STANDARDS REOUIREMENTS. As used in
the following provision, the term "laborers" and "mechanics" include watchers and guards.
a. Overtime Requirements. Neither the Contractor nor any Subcontractor contracting for
any part of the Project which may require or involve the employment of laborers or mechanics shall
require or permit any such laborer or mechanic in any workday in which he or she is employed on such
work to work in excess of eight (8) hours per day, or in any workweek in which he or she is employed
on such work to work in excess of forty (40) hours in such workweek, unless such laborer or mechanic
receives compensation at a rate not less than one and one-half (I \1,) times the basic rate of pay for all
hours worked in excess of eight (8) hours in such workday or forty (40) hours in such workweek.
b. Violation; Liabilitv for Unpaid Wages; Liquidated Damages. In the event of any
violation of the clause set forth in paragraph a. above, the Contractor and any Subcontractor
responsible therefore, shall be liable for the unpaid wages. In addition, the Contractor and
Subcontractor shall be liable to the Agency for liquidated damages. Such liquidated damages shall be
computed with respect to each individual laborer or mechanic, including watchers and guards,
employed in violation of the clause set forth in paragraph a. above, in the sum of Ten Dollars ($10) for
each calendar day on which such individual was required or permitted to work in excess of the
standard workday of eight (8) hours or workweek of forty (40) hours without payment of the overtime
wages required by the clause set forth in paragraph a. above.
c. Withholding for Unpaid Wages and Liquidated Damages. The Agency shall, upon its
own action or upon written request of an authorized representative of the Department of Industrial
Relations, withhold or cause to be withheld, from any monies payable on account of work performed
by the Contractor or Subcontractor under any such contract or any other contract with the same
Contractor, or any other contract subject to the California work hours and safety standards
requirements which is held by the same Contractor, such sums as may be determined to be necessary to
satisfy any liabilities of such Contractor or Subcontractor for unpaid wages and liquidated damages as
provided in the clause set forth in paragraph b. above.
8
d. Working conditions. Neither the Contractor nor any Subcontractor may require any
laborer or mechanic employed in the performance of any contract to work in surroundings or under
working conditions that are unsanitary, hazardous or dangerous to his or her health or safety as
determined under construction safety and health standards issued by the Department of Industrial
Relations.
e. Subcontracts. The Contractor and any Subcontractor shall insert in any subcontracts the
clauses set forth in paragraphs a. through d. and also a clause requiring the Subcontractor to include
these clauses in any lower tier subcontracts. The Contractor shall be responsible for compliance by
any Subcontractor or lower tier Subcontractor with the clauses set forth in paragraphs a. through d.
17. NONDISCRIMINATION. The Contractor, with regard to the work performed by it during
the Contract, shall not discriminate on the grounds ofrace, color, or national origin in the selection and
retention of Subcontractors, including procurements of materials and leases of equipment. The
Contractor shall not participate either directly or indirectly in the discrimination prohibited by Section
21.5 of the Regulations, including employment practices when the Contract covers a program set forth
in Appendix B of the Regulations.
18. CIVIL RIGHTS. The Contractor assures that it will comply with pertinent statutes,
Executive Orders and such rules as are promulgated to assure that no person shall, on the grounds of
race, creed, color, national origin, sex, age or handicap be excluded from participating in any activity
conducted with or benefiting from Federal assistance. This Provision binds the Contractor from the
bid solicitation period through the completion of the Contract. This provision shall be inserted in all
subcontracts, subleases and other agreements at all tiers.
19. SOLICITATIONS FOR SUBCONTRACTS, INCLUDING PROCUREMENTS OF
MATERIALS AND EQUIPMENT. In all solicitations either by competitive bidding or negotiation
made by the Contractor for work to be performed under a subcontract, including procurements of
materials or leases of equipment, each potential Subcontractor or supplier shall be notified by the
Contractor of the Contractor's obligations under this Contract and the Regulations relative to
nondiscrimination on the grounds of race, color or national origin.
20. INFORMATION AND REPORTS. The Contractor shall provide all information and reports
required by the Regulations or directives issued pursuant thereto and shall permit access to its books,
records, accounts, other sources of information and its facilities as may be determined by the Agency
to be pertinent to ascertain compliance with such Regulations, orders, and instructions. Where any
information required of a Contractor is in the exclusive possession of another who fails or refuses to
furnish this information, the Contractor shall so certify to the Agency, as appropriate, and shall set
forth what efforts it has made to obtain the information.
21. SANCTIONS FOR NONCOMPLIANCE. In the event of the Contractor's noncompliance
with the nondiscrimination provisions of this contract, the Agency shall impose such contract sanctions
as determine to be appropriate, including but not limited to:
a. Withholding of payments to the Contractor under the contract until the
Contractor complies, and/or
b. Cancellation, termination or suspension of the contract, in whole or in part.
9
22. INSPECTION OF RECORDS. The Contractor shall maintain an acceptable cost
accounting system. The Agency, the Comptroller General of the United States or any of their duly
authorized representatives shall have access to any books, documents, paper, and records of the
Contractor which are directly pertinent to this Contract or the Project for the purposes of making an
audit, examination, excerpts, and transcriptions. The Contractor shall maintain all required records for
three (3) years after the Agency makes final payment and all other pending matters are closed.
23. RIGHTS IN INVENTIONS. All rights to inventions and materials generated under this
Contract are subject to regulations issued by the Agency. Information regarding these rights is
available from the Agency.
24. BREACH OF CONTRACT TERMS. Any violation or breach of terms of this Contract
on the part of the Contractor or its subcontractors may result in the suspension or termination of this
Contract or such other action that may be necessary to enforce the rights of the Agency under this
Contract. The duties and obligations imposed by the Contract Documents and the rights and remedies
available thereunder shall be in addition to and not a limitation of any duties, obligations, rights and
remedies otherwise imposed or available by law. This Contract shall be interpreted under the laws of
the State of California. The venue for any legal proceeding to interpret any provisions of this Contract
shall be in the Superior Court of the County of San Bernardino. In the event that legal proceedings may
be initiated by one (I) party to enforce its rights under this Contract, than the prevailing party in such
legal proceedings shall be entitled to recover from the other party, its reasonable attorneys' fees either
in such legal proceedings or in a separate action to recover such reasonable attorneys' fees. In the case
of the Agency, the words "reasonable attorneys' fees" include the cost and expenses calculated on an
hourly basis, of all lawyers retained by the Agency in connection with the legal representation of the
Agency in any matter arising from this Contract, including, without limitation, attorneys in the Office
of the City Attorney and Agency General Counsel.
25. TERMINATION OF CONTRACT BY AGENCY.
a. The Agency may, by written notice, terminate this Contract in whole or in part at any
time, either for the Agency's convenience or because of the Contractor's failure to fulfill its
Contract obligations. Upon receipt of such notice, services shall be immediately discontinued
(unless the notice directs otherwise) and all materials as may have been accumulated in
performing this Contract, whether completed or in process, delivered to the Agency.
b. If the termination is for the convenience of the Agency, an equitable adjustment in the
Contract price shall be made, but no amount shall be allowed for anticipated profit on
unperformed services.
c. If the termination is due to failure to fulfill the Contractor's obligations, the Agency
may take over the work and prosecute the same to completion by Contract or otherwise. In
such case, the Contractor shall be liable to the Agency for any additional cost occasioned to the
Agency thereby.
d. If, after notice of termination for failure to fulfill Contract obligations, it is determined
that the Contractor had not so failed, the termination shall be deemed to have been effected for
the convenience of the Agency. In such event, adjustment in the contract price shall be made
as provided in paragraph 2 of this clause.
10
e. The rights and remedies of the Agency provided in this clause are in addition to any
other rights and remedies provided by law or under this contract.
26. INCORPORATION OF PROVISIONS. The Contractor shall include the provisions of this
Contract in every subcontract, including procurements of materials and leases of equipment, unless
exempt by the Regulations of directives issued pursuant thereto. The Contractor shall take such action
with respect to any subcontract or procurement as the Agency may direct as a means of enforcing such
provisions including sanctions for noncompliance. Provided, however, that in the event the Contractor
becomes involved in, or is threatened with, litigation with a Subcontractor or supplier as a result of
such direction, the Contractor may request the Agency to enter into such litigation to protect the
interests ofthe Agency and, in addition, the Contractor may request the United States to enter into such
litigation to protect the interests of the United States and the Department of Industrial Relations to
protect the interests of the State of California.
27. CONTRACTOR CLAIMS OF $375,000 OR LESS. Claims by the Contractor relating to the
Project for (a) a time extension, (b) money or damages arising from work done by, or on behalf of, the
Contractor on the Project for which payment is not expressly provided for or to which the Contractor is
not otherwise entitled, or (c) an amount that is disputed by the Agency, with a value of $375,000 or
less, are subject to the claims procedures set forth in California Public Contract Code Sections 20104,
et seq., except as otherwise provided in this Contract and the incorporated documents, conditions and
specifications. A copy of California Public Contract Code Sections 20104 through 20104.6 is attached
to this Contract.
28. ASSIGNMENT OF CERTAIN RIGHTS TO THE AGENCY. In entering into this Contract or
a subcontract to supply goods, services, 0r materials pursuant to this Contract, the Contractor and/or
Subcontractor offers and agrees to assign to the Agency all rights, title, and interest in and to all causes
of action it may have under Section 4 of the Clayton Act (15 U.S.C. Sec. IS) or under the Cartwright
Act (Chapter 2 (commencing with Section 16700) of Part 2 of Division 7 of the Business and
Professions Code), arising from purchases of goods, services, or materials pursuant to this Contract or
the subcontract. This assignment shall be made and become effective at the time the Agency tenders
final payment to the Contractor, without further acknowledgement by the parties.
29. ENERGY CONSERVATION REQUIREMENTS. The Contractor agrees to comply with
mandatory standards and policies relating to energy efficiency that are contained in the state energy
conservation plan issued in compliance with the Energy Policy and Conservation Act (Public Law 94-
163)
30. PROTECTION. The Contractor shall at all times provide protection against weather, rain,
wind, storm and heat so as to maintain all work, materials, apparatus and fixtures free from injury and
damage. At the end of a day's work, all new work, and the premises, likely to be damaged by failure
to provide protection as required above shall be replaced or repaired at Contractor's expense.
31. CONTRACTORS BEST SKILL. The Contractor shall supervise and direct the work using its
best efforts, skill and attention to ensure the workmanship and materials are of good quality and that
the work is completed in accordance with the Contract. Contractor shall be solely responsible for all
construction means, methods, techniques, sequences and procedures; safety on the work; and
coordinating all portions on the Project to be performed by Contractor's Laborers, Employees,
Vendors and Subcontractors, ifany.
II
32. UTILITY SERVICES. The Contractor will be able to use existing utilities without charge,
including electric power and water. If Contractor must disconnect or otherwise interrupt such services,
including plumbing fixtures, to effect repairs or replacement, the use or availability of such services
shall not be deprive the Project's occupants, unless the Project's occupants has been relocated. Where
disruptions or disconnections will occur other than during normal business hours, Contractor shall
obtain approval of Project's occupant, at least twenty-four (24) hours prior to such interruption.
33. LEAD-BASED PAINT. The Contractor agrees that the use of any lead-based paints is strictly
prohibited and shall not be used on this Project. Contractor agrees to submit to the Agency an
Abatement Plan pursuant to the State of California Department of Health Services Regulations, and
pursuant to the South Coast Air Quality Management District, prior to the commencement of work on
the Project, if applicable.
The Agency assumes no liability for damages for personal injury, illness, disability, or death to the
Contractors, or to any Consultant or employees, agents, or invitees of the Contractor or any Consultant,
or to any other person, including members of the general public, arising from or incident to the Agency
Investigation Work or other activity causing or leading to contact of any kind whatsoever with lead-
based paint on the Agency Site, whether the Agency has properly warned, or failed to properly warn,
any persons injured.
The Contractor agrees to cause all removal, transportation and disposal of the lead-based paint removal
pursuant to this Contract and the Contract Documents without any cost or liability to the Agency
whatsoever. The Contractor shall execute all required documents and pay such fees, taxes and other
charges and assessments as may be charged, levied or assessed as to the removal, transportation and
disposal of the lead-based paint pursuant to this Contract. The Contractor represents and warrants that
all such additional fees, taxes and other charges and assessments are included within the Contract price
set forth in Section 3 hereof, if applicable.
34. ASBESTOS CONTAINING MATERIALS. The Contractor agrees to submit to the Agency an
Abatement Plan pursuant to the State of California Department of Health Services Regulations, and
pursuant to the South Coast Air Quality Management District, prior to the commencement of work on
the Project, if applicable.
The Agency assumes no liability for damages for personal injury, illness, disability, or death to
the Contractors, or to any Consultant or employees, agents, or invitees of the Contractor or any
Consultant, or to any other person, including members of the general public, arising from or incident to
the Agency Investigation Work or other activity causing or leading to contact of any kind whatsoever
with Asbestos on the Agency Site, whether the Agency has properly warned, or failed to properly
warn, any persons injured.
The Contractor agrees to cause all removal, transportation and disposal of the asbestos removal
pursuant to this Contract and the Contract Documents without any cost or liability to the Agency
whatsoever. The Contractor shall execute all required documents and pay such fees, taxes and other
charges and assessments as may be charged, levied or assessed as to the removal, transportation and
disposal of the asbestos pursuant to this Contract. The Contractor represents and warrants that all such
additional fees, taxes and other charges and assessments are included within the Contract price set
forth in Section 3 hereof, if applicable.
12
35. HAZARDOUS WASTE NOTIFICATION. The Contractor shall promptly, and before the
following conditions are disturbed, notify the Agency, in writing, of any of the following:
(I) Material that the Contractor believes may be hazardous waste, as defined in Section 25117 of
the California Health and Safety Code that is required to be removed to a Class I, Class II, or Class III
disposal site in accordance with provisions of existing law.
(2) Subsurface or latent physical conditions at the site differing from those indicated by
information about the site made available to bidder prior to the deadline for submitting bids.
(3) Unknown physical conditions at the site of any unusual nature, different materially from those
ordinarily encountered and generally recognized as inherent in work of the character provided for in
this Contract.
After promptly investigating the conditions of such material, if the Agency finds that the conditions
do materially differ from that indicated in the information about the site in the bid packet made
available to bidders prior to the deadline for accepting bids, or if the Agency finds that the conditions
do involve hazardous waste, the Agency shall cause a decrease or increase in the Contractor's cost of
the Project, or time required for performance of any part of the work for the Project, and shall issue a
written Project Change Order under the procedures described in Section II of this Contract. In the
event that a dispute arises between the Contractor and the Agency regarding whether the conditions
materially differ, or whether the conditions involve hazardous waste, or whether such conditions cause
a decrease or increase in the Contractor's cost of, or time required for, performance of any part of the
work for the Project, the Contractor shall not be excused from any scheduled completion date provided
for by this Contract, but shall proceed with all work to be performed under this Contract, retaining any
and all rights provided by this Contract or law which pertain to the resolution of disputes under this
Contract.
36. CLEANUP. The Contractor shall keep the subject Project clean and orderly during the course
of the work. Upon completion of the work contemplated by this Contract, the Contractor shall cause
all debris resulting from such construction to be removed from the subject Project and shaIlleave the
subject Project in a neat and "broom-clean" condition.
37. BUlSNESS REGISTRATION CERTIFICATION. The Contractor warrants that it possesses, or
shall obtain immediately after the execution and delivery of this Contract, and maintain during the
period of time that this Contract is in effect, a business registration certification pursuant to Title 5 of
the City Municipal Code, together with any and all other licenses, contractor license, permits,
qualification, insurance and approvals of whatever nature that are legally required to be maintained by
the Contractor to .conduct its business activities within the City.
1/1
1/1
1/1
1/1
I3
IN WITNESS WHEREOF, three identical counterparts of this Contract, each of which shall for
all purposes be deemed an original thereof, have been duly executed by the parties hereinabove named,
on the day and year first herein written.
REDELOPMENT AGENCY OF THE CITY OF SAN BERNARDINO:
a public body, corporate and politic ("Agency" or "Project Administrator")
By:
Emil A. Marzullo, Interim Executive Director
Approval as to Form and Legal Content:
By: C/~{1~J
Agency Co se
CONTRACTOR:
Francisco Construction
BY:~' ~~("~ (7~
Felix ranC1SCO - Owner/Operator
Dated: jO- /0 -() if
:r svK.,//;;J....
;;I55/IJ l) S SClt1 &n/1.Qv-J~() CA 9:;'~DI
Type or Print Contractor'slBidder's Business Address (City, State, and Zip Code)
f3
7;) 77 ~-
13
Contractor's License
Contractor License Classification
.,
7'-/~-/L)
Contractor's License Expiration Date
Bond Number
14