Loading...
HomeMy WebLinkAbout1987-022 1 RESOLUTION NO. 87-22 2 RESOLUTION OF THE CITY OF SAN BERNARDINO AWARDING A CONTRACT TO WICKUM CONSTRUCTION FOR BLEACHER ADDITIONS AND ALTERATIONS TO JOHN FISCALINI 3 FIELD IN PERRIS HILL PARK. 4 BE IT RESOLVED BY THE MAYOR AND COMMON COUNCIL OF THE CITY OF SAN BERNARDINO AS FOLLOWS: 5 6 7 SECTION 1. Wickum Construction is the lowest responsible bidder for: Construction of Bleacher Additions and Alterations to John Fiscalini Field in Perris Hill Park, in accordance with Plan No. 7150, for the 8 total amount of $229,000.00, a contract is awarded to said bidder accordin9ly, 9 but such award shall be effective only upon the contract being fully executed 10 by the parties; all other bids therefor are hereby rejected; and the Mayor 11 is hereby authorized and directed to execute said contract on behalf of the 12 City; a copy of the contract is attached hereto, marked Exhibit "A" and 13 incorporated herein by reference as fully as though set forth at length. 14 SECTION 2. Execution and Amendments. This contract and any 15 amendments or modifications thereto shall not take effect or become operative 16 until fully signed and executed by the parties and no party shall be 17 obligated hereunder until the time of such full execution. No oral 18 agreements, amendments, modifications or waivers are intended or authorized 19 and shall not be implied from any act or course of conduct of any party. 20 21 I HEREBY CERTIFY that the foregoing resolution was duly adopted by the Mayor and Common Council of the City of San Bernardino at a 22 23 24 25 26 27 28 1-16-87 reaular meeting thereof, held on the 19th day of January , 1987, by the following vote, to-wit: AYES: Council Members Reilly 0"i..1, Friu:ier, Srri"k1..r NAYS: Council Members RRrr~n~. H..rn~nne7 ABSENT: None . pC,.....!"':'I.I"':""._r"'..\' .....1 r'r" CITY OF SAN BERNARD I NO STATE OF CALIFORNIA CONTRACT OOClI4ENTS PLAN AND SPECIAL PROVISIONS NO. 7150 F~ BLEACHER ADDITIONS AND ALTERATIONS TO JOHN FISCALINI FIELD IN PERRIS HILL PARK DIVISION OF ENGINEERING DEPARTMENT OF PUBLIC WORKS CITY OF SAN BERNARD I NO DECEMBER 31. 1986 B I OS W ILL BE RECE I VED lP TO THE I-IOI.ft OF 2:00 P.M.. ON JANUARY 16. 1986 ~ r7 '"', ....., ,.. I - c:/- ""-- L A WAINSCOTT a ASSOCIATES _1.1 '_1_ "A II January 9, 1987 File No. 6-1.41H ADDENDUM NO. ONE FOR BLEACHER ADDITION AND ALTERATIONS AT JOHN FISCALINI FIELD PERRIS HILL PARK PLAN NO. 7150 The contract plans and documents for this project are hereby amended as follows: 1. SECTION 4 -- "CONSTRUCTION SCHEDULE AND COMMENCEMENT OF WORK, TIME OF COMPLETION AND LIQUIDATED DAMAGES", is hereby changed to read as foll ows: 4-1.01 -- Attention is directed to the provisions in Section 6-1 "Construction Schedule and Commencement of Work", in Section 6- 7.1, "Time of Completion", and in Section 6-9, "Liquidated Damages", of the Standard Specifications and these Special Provisions. The Contractor shall diligently prosecute the work to completion before the expiration of 50 Working Days from the date of the "Notice to Proceed". It is the City's intention for all work to be completed by April 3, 1987. The Contractor shall pay to the City of San Bernardino the sum of $ 500.00 per day, for each calendar days delay in finishing the work in excess of the date prescribed above. 2. SECTION 6-1.06 "PAYMENTS" is hereby changed to read as follows: Attention is directed to Section 9-3 "Payments", and 9-3.2 "Partial and Final Payment", of the Standard Specifications and these Special Provisions. . '. Partial payments will be made for materials fabricated and delivered to the job-site. Final payment shall be made only after written acceptance of the work by the City Engineer. 3. All riser boards for bleacher units "A", "B", "c" shall be gold anodized. 4. Backrests and seats for stadium chairs, (Sections "A" and "B") and backrests for plank-type seating (Section "C") shall be painted with powder coat baked enamel in color, or colors as approved by the Engineer. Contractor shall submit a color chart to the Engineer for color selection (5) five days after award of contract. 5. Sheets 3 through 6 covering Sections 2 through 6 of the Special Provisions are hereby added to the Specifications. All bidders shall indicate receipt of Addendum No. One in their bids. By: Da te: I~',(;) -2- SECTION 2 2-1 PROPOSAL REQUIREMENTS AND CONDITIONS 2-1.01 GENERAL Bids must be submitted on the proposal form contained herein. All bids or proposals shall be signed, sealed and accompanied by cash, cashier's check, certified check or bid bond made payable to the City of San Bernardino, in the amount of ten percent (10%) of the bid. Such cash, check or bond shall be given as a guarantee that the bidder will enter into the contract, if awarded to him. In the event the bidder, to whom the contract is awarded, refuses to execute said contract, the use by the public of the improvements will be delayed and the public will suffer great damage. From the nature of the case, it would be extremely difficult and impractical to fix said amount of damage. Therefore, the City and the bidder agree that the proposal guarantee of 10% of the bid shall be oaid to the City upon the conditions set forth above as liquidate'd damages and not as a forfeiture. Bid bonds shall be underwritten by a surety company having a rating in Best's most recent Insurance Guide "A" or better. SECTION 3 3-1 AWARD AND EXECUTION OF CONTRACT 3-1.01 GENERAL Award of the contract will normally be made by the Mayor and Common Council at the subsequent Council Meeting after opening of the bids. The bidder, to whom the contract is awarded, shall file with the Engineer all required bonds and insurance policies, and execute the contract, within 5 calendar days after receiving notification of the award. Failure to file the stipulated documents and execute the contract within the prescribed time shall constitute good and sufficient grounds for recession of the ward and payment of 10% of the bid to the City as liquidated damages. 3-1.02 CONTRACT BONDS The Payment and Faithful Performance Bonds shall be filed with the Engineer before the contract is executed by the City in accordance with Section 2-4, "CONTRACT BONDS," of the Standard Specifications. SECTION 4 4-1, CONSTRUCTION SCHEDULE AND COMMENCEMENT OF WORK, TIME OF COMPLETION AND LIQUIDATED DAMAGES 4-1.01 Attention is directed to the provisions in Section 6-1, "Construction Schedule and Commencement of Work," in Section 6-7.1, "Time of Completion," and in Section 6-9, "Liquidated Damages," of the Standard Specifications and these special provisions. SPECIAL PROVISIONS 00800-2 342.041 The Contractor shall diligently prosecute the work to completion before the 3rd Day of April 1987. The Contractor shall pay to the City of San Bernardino the sum of $500.00 per day, for each calendar days delay in finishing the work in excess of the date prescribed above. SECTION 5 5-1 LEGAL REQUIREMENTS 5-1.01 LIABILITY INSURANCE The Contractor's attention is directed to Section 703, "Liability Insurance," of the Standard Specifications, providing that the contractor shall furnish the City with a policy or certificate of liability insurance as prescribed therein, prior to execution of the contract. 5-1.02 WORKMEN'S COMPENSATION INSURANCE The Contractor's attention is directed to Section 7-4, "Workmen's Compensation Insurance," of the Standard Specifications, providing that the contractor shall file a signed certification Certificate of Workmen's Compensation Insurance before execution of the contract. 5-1.03 PAYMENT OF PREVAILING WAGE RATE The Contractor and all sub-contractors shall pay each craft or workmen employed on this project not less than the prevailing wage rates specified in Resolution No. 12846 of the Mayor and Common Council of the City of San Bernardino. The Engineer shall have the right to interview any craft or workman on the project site in order to verify payment of prevailing wage rates in accordance with Resolution No. 12846. 5-1.04 PAYROLL RECORDS The Contractor's attention is directed to the following provisions of Labor Code Section 1776 (Stats. 1978, Ch. 1249). The Contractor shall be responsible for the compliance with these provisions by his subcontractors. (a) The contractor and all subcontractors shall keep an accurate payroll record, showing the name, address, social security number, work classification, straight time and overtime hours worked each day and week, and the actual per diem wages paid to each journeyman, apprentice. worker, or other employee employed by him or her in connection with the public works. (b) The payroll be certified and reasonable hours at following basis: records enumerated under subdivision (a) shall shall be available for inspection at all the principal office of the contractor on the 1) A certified copy of an employee's payroll record shall be made available for inspection or furnished to such employee or his or her authorized representative on request. SPECIAL PROVISIONS 00800-3 342.041 (c) Each contractor shall file a certified copy of the records enumerated in subdivision (a) with the Engineer on a weekly basis. It will be the contractor's responsibility to submit the records enumerated in subdivision (a) for all of his subcontractors, in addition to his own employees. Failure to submit the records enumerated in subdivision (a) on a timely basis shall constitute good and sufficient reason for withholding the partial payment for work accomplished. 5-1.05 BUILDERS RISK INSURANCE The Contractor shall secure and maintain in force a Builders Risk Insurance Policy in the amount of the contract price of all buildings that are included in the contract award during the life of his contract. A copy of the Builder's Risk Insurance shall be furnished to the City by the Contractor. The contractor will provide Builder's Risk "All Insurance, in an amount not less than the contract award naming the City and the consultant as additional insured. Risk" amount, SECTION 6 6-1 GENERAL 6-1.01 INCREASED OR DECREASED QUANTITIES If the total pay quantity of any item of work, subject to the provisions in Section 3-2.2.1, "Increased or Decreased Quantities," of the Standard Specifications varies by more than 25 percent, compensation payable to the Contractor will be determined in accordance with said Section 3-2.2.1 and these special provisions. When the compensation payable for the number of units of an item of work performed in excess of 125 percent of the Engineer's estimate is less than $1,500 at the applicable contract unit price, the Engineer reserves the right to make no adjustment in said price if he so elects, except that an adjustment will be made if requested in writing by the Contractor. Such Contractor's request shall be accompanied by adequate, detailed data to support costs of the item. Should the total pay quantity of any item of work required under the contract be less than 75 percent of the Engineer's Estimate therefore, the Engineer reserves the right to make no adjustment in said price if he so elects, except that an adjustment will be made if requested in writing by the Contractor. Such contractor's request shall be accompanied by adequate, detailed data to support costs of the item. 6-1.02 SOUND CONTROL REQUIREMENTS The Contractor shall comply with Chapter 8.54 of the City of San Bernardino Municipal Code regulating and prohibiting loud. unnecessary and excessive noises. SPECIAL PROVISIONS 00800-4 342.041 Each internal combustion engine, used for any purpose on the job or related to the job, shall be equipped with a muffler of a type recommended by the manufacturer. No internal combustion engine shall be operated on the project without said muffler. Said noise level requirement shall apply to all equipment on the job or related to the job, including but not limited to trucks, transit mixers or transit equipment that mayor may not be owned by the Contractor. The use of loud sound signals shall be avoided in favor of light warnings except those required by safety laws for the protection of personnel. 6-1.03 LICENSE Business License from the execution of the contract. The Contractor shall obtain a City City of San Bernardino, prior to 6-1.04 EXTRA WORK Any extra work done shall conform to the provisions in Section 3-3, "Extra Work ," of the Standard Specifications. However, equipment rental rates shall conform to State of California Business and Transportation Agency, Department of Transportation, Division of Construction, "LABOR SURCHARGE AND EQUIPMENT RENTAL RATES," latest Edition, unless the extra work is done for a negotiated price. Change order for extra work must be signed by the Contractor, Structural Engineer and approved by OSHA, City Council before extra work can commence. 6-1.05 HOURS OF LABOR In the event that the Engineer is required by the Contractor's operations to work more than eight (8) hours in any given day, or more than forty (40) hours in any given week, or on any Saturday, Sunday or Holiday, in the setting of Lines and Grades or performing inspections, the Contractor shall pay an amount to the City equal to one and a half (1 1/2) times the Engineer's normal wages and fringe benefits. Such amount shall be deducted from the next following progress payments. 6-1.06 PAYMENTS Attention is directed to Section 9-3, "Payments," and 9-3.2, "Partial and Final Payment," of the Standard Specifications and these Special Provisions. No partial payment will be made for any materials on hand which are furnished but not incorporated in the work. Final payment shall be made only after written acceptance of the work by the City Engineer. SPECIAL PROVISIONS 00800-5 342.041 TABLE OF CONTENTS DIVISION 0 BIDDING REQUIREMENTS 00020 NOTICE INVITING BIDS 2 00300 PROPOSAL 3 00430 SUBCONTRACTORS LIST 1 00600 CERTIFICATION FORM 1 00800 SPECIAL PROVISIONS 5 DIVISION 13 SPECIAL CONSTRUCTIONS 13125 GRANDSTANDS AND BLEACHERS AGREEMENT 2 Engineer's Estimate $ 210,000 NOTICE INVITING BIDS NOTICE IS HEREBY GIVEN that the City of San Bernardino will receive bids or proposals for: BLEACHER ADDITIONS AND ALTERATIONS TO JOHN A. FISCALINI FIELD IN PERRIS HILL PARK. IN ACCORDANCE WITH SPECIAL PROVISIONS NO. 7150 ON FILE IN THE OFFICE OF THE CITY ENGINEER. ROOM 405. CITY HALL. Deliver all bids to the City Engineer's Office, Room 405, City Hall, 300 North "D" Street, San Bernardino, California, with the specification title and number clearly marked on the outside of the envelope. Said bids or proposals will be received up to the hour of 2:00 p.m. Januart 16 , 1987, at which time all of said bids or proposals w 11 be publicly opened, examined and declared in the City Engineer's Conference Room, 405. No bid will be received unless it is made on a proposal form furnished by the City. All bids or proposals shall be signed, sealed and accompanied by cash, cashier's check, certified check or bid bond made payable to the City of San Bernardino, in the amount of ten percent (10S) of the bid. Such cash, check or bond shall be given as a guarantee that the bidder will enter into the contract if awarded to him. In the event the bidder refuses to execute said contract, the use by the public of the improvements will be delayed, and the public will suffer great damage. From the nature of the case, it would be extremely difficult and impractical to fix said amount of damage. Therefore, the Ci ty and the bi dder agree tha t the above sum of 10S s ha 11 be pa i d to the City upon the condition above set forth as liquidated damages and not as a forfeiture. All bonds furnished pursuant to this notice must be underwritten by a surety company having a rating in Best's most recent Insurance Guide of "A" or better. Pursuant to law, the Mayor and Common Council of the City of San Bernardino, by Resolution No. 12846 and any and all amendments thereto which are hereby referred to and made a part there of by reference as fully as though set forth at length herein, have acertained and determined the general prevailing rate of per diem wages, and of per diem wages for legal holidays and over-time work for each craft or type of workman needed in the execution of contracts under jurisdiction of said Mayor and Common Council. Said prevailing rates of wages shall conform to "General Prevailing Wage Determination made by the Director of Industrial Relations," filed in the Office of the City Clerk, which are made a part of said Resolution No. 12846 and amendments thereto. The Contractor may substitute securities for any monies withheld by the Agency to ensure performance under the contract as provided for in Section 4590 of the California Government Code and Section 10263 of the California Public Contract Code. It shall be mandatory upon the contractor to whom the contract is awarded and upon any sub-contractor under him to pay not less than said specified rates to all laborers, workmen, and mechanics employed by them in the execution of the contract, and to prevent discrimination in the employment of persons because of race, creed, color, or national origin, as set forth in the provisions of Resolution No. 7414 of the Mayor and Common Council of the City of San Bernardino. No bid will be accepted from a contractor who does not possess a Class "A" or "C-61" license issued pursuant to provisions of Chapter 9, 01Vls1on III of the Business and Professional Code. The City of San Bernardino reserves the right to bids. No bidder may withdraw his bid within 30 the date of the bid opening. Plans and specifications may be obtained from the City Engineer's Office, Room 405, City Hall, 300 North "0" Street, San Bernardino, California 9241B, upon a non-refundable payment of $ 5.00 for each set. reject any and all working days from CITY OF SAN BERNARDINO fI~/ SHAUNA Cl ,C ty erk NOTICE TO ADVERTISE SPECIFICATION No.........7.J~.9................. ,HALL APPEAR IN FIRST ISSUE NOT LATER THAN. DA TE.......yy~?a.~~...~!.~~!.?7. SECOND PUBLICATION fJX7 DAYS LATER SIGNATURF ~~//J?d ~IiDATE (0d~ PROPOSAL FORM TO THE MAYOR AND COMMON COUNCIL OF THE CITY OF SAN BERNARDINO The undersigned declares that he has carefully examined the location of the proposed work, that he has examined the plan and read the accompanying instructions to bidders and hereby proposed to furnish any and all required labor, materials, transportation and service for the BLEACHER ADDITIONS AND ALTERATIONS TO JOHN A. FISCALINI FIELD IN PERRIS HILL PARK, in strict conformity with Plans and Special Provisions No. 7150, City of San Bernardino, Department of Public Works, and also in accordance with Standard Specifications for Public Works Construction, 1985 Edition, and the 1982 edition of the UNIFORM BUILDING CODE, CALIFORNIA ADMINISTRATIVE CODE TITLE 24, PART 3, and he proposes and agrees if the City of San Bernardino, in the form of the copy of the contract annexed hereto, to provide all necessary machinery, tools, apparatus and other means of construction, and to do all the work and furnish all the materials specified in the contract, in the manner and time therein prescribed, and that he will take in full payment therefor the lump sum price, to-wit: PROPOSAL 00300-1 ....,..... ^J ITEM 1. '3/.'1 n/. BID SCHEDULE Additions and alterations of bleachers per plan and specs including materials and labor (concrete work not a part of this contract) Lump Sum ()d $ 221. 000. - . PROPOSAL 00300-2 In case of a discrepancy between words and figures, the words shall prevail. It is the understanding of the undersigned hereinabove described shall be commenced within 5 date of the "Notice to Proceed ," and shall be accepted by April 3, 1987. that the work days from the completed and The undersigned further agrees that in cases of default in executing the contract, or furnishing necessary bonds, all within the specified time, the proceeds of the Bidder's Guaranty accompanying this proposal shall be paid to the City of San Bernardino as liquidated damages. Licensed in accordance with an registration of contractors, License Cl 'f' t' ..14' I' ...,." 'C fI" aSS1 1ca 10n . _ ~. -. - act providing for the No. J 3...:1.L!2....___ ' FIRM NAME: W/" k" CI -- c" ~ ;s f"/lll c-f-,;,,,, ~"lIG'UE1> BUSINESS ADDRESS: 43 8"9 U. FL.-I- uff A- I/E. t::.#9f.3<1lJ SIGNATURE OF BIDDER:'r ~4~2- LtJ~/.,.......- tP.lJ...n~ If an individual, so state. If a firm or co-partnership, state the firm name and give the names of all individuals, co-partners composing the firm. If a corporation, sate legal name of the corporation, also the names of the president, secretary, treasurer and manager thereof. lA~ t.-k tint E'- rt>.1-I :r. LIJH sf Wltkn.N\ PA ~ E IL~-"....t .5 A- AJ 1=()~ C> W,t../(I4M P-4 j2. Trl S /l.. .ro t Telephone No. (2D9) 7Z2 -SS"i!.b Dated I ~ I' , 198 1 ;4 PP& ,A./PLf N\ Nt>. K~G'J / '+")6 TE..l:> 1 6!X'V . . PROPOSAL 00300-3 ?,/,,? N. DESIGNATION OF SUB-CONTRACTORS In compliance with the Provisions of Section 4100-4108 of the Government Code of the State of California, and any amendments thereof, each bidder shall set forth the name and location of each sub-contractor who will perform work or labor of render service to the contractor. TRADE $k."/~"J 342.04 SUB-CONTRACTOR CITY LICENSE NO. CLASSIFICATION r;8"'~1J"LSl'Ahil' C" ,SMf ,en"'/U~ L~ ~ C-bl SUBCONTRACTORS LIST 00430-1 CERTIFICATION I am aware of, will comply with, Section 3700 of the Labor Code, requiring employer to insure against liability for Workers' Compensation or to undertake self insurance before commencing any of the work. Contractor NAME OF FIRM: W, c-k~ C() ,y.f RvJ~~/" r~ 7.-hlL4'h ?4-E- 1-N IS. ~ /-/~-t5'7 . BY: TITLE: DATE: CERTIFICATION FORM 00600-1 342.04 ci\l ~ FIREMAN'S FUND INSURANCE COMPANY e 0 THE AMERICAN INSURANCE COMPANY o NATIONAL SURETY CORPORATION FIREMAJI5 FUJIII 0 ASSOCIATED INDEMNITY CORPORATION ""'.lI:Il:lIIII'IUIIIS 0 AMERICAN AUTOMOBILE INSURANCE COMPANY BID OR PROPOSAL BOND KNOW AU. MEN BY 1lIESE PRESENTS: That We, Wickum Construction 4389 West Elliott Merced, Ca. 95340 (hereinafter called the principal). as principal, and Fireman I s Fund Insurance Compa ' a corporation organ. ized and doing business under and by virtue of the laws of the Stale of California ,and ~f; licensed for the purpose of making, guaranteeing or becoming sole surety upon bonds or undertakings required or authorized by the laws of the State of as Surety, are held and firmly bound unto City of San Bernadino (hereinafter called the Obligee) in the jusl and Iu11 sum of Ten Percent of Amount Bid Dollars ($ 10% of Amt. bi)dlawful money of the United States of America, for the payment of which, well and truly to be made, we hereby bind ourselves and our and each of our successors and assigns, jointly and severally, firmly by these presents. THE CONDlTION OF THIS OBLIGATION IS SUCH THAT, WHEREAS, the above bounden principal as aloresaid, is about to hand in and submit to the obligee a bid or proposal for the Bleacher addition and Alteration to the field, Parris Hill Park, San Bernadino S.P. NO. 7150 in accordance with the plans and specifications filed in the office of the obligee land under the notice inviting proposals therefor. NOW, THEREFORE, if the' bid or proposal of said principal shall be accepted. and the contract for such work be awarded to the principal thereupon by the said obligee, and said principal shall enter into a contract and bond for the completion of said work as required by law, then this obligation to be null and void, otherwise to be and remain in full force and effect. A'ITORNEY IN FACT ACKNOWLEDGMENT ~= ~~_~~=_____"""_"" t SI. On Ihis ________1.4.tlL__""_,."."..__,,._..day of """""""J.anllar.y """""."',,, in lhe year """"J,,1l8.1,__,_,,___,_, before me, a Notary Public in and for said ....w....w._w.w.w_.wMe..I:.C.e.d.......w.....w.w...._._~.w...._.w..w..............w.w......... ...County. State of California. residing therein, duly commissioned and sworn, personally appeared J osep h _A~Er.o.i.e.:t.:t..i.,____,,_._,,_""'_""""'_""_, 0 perIHdy _ 10 _, 0 .........10 _ OD !be .... oflOlWactory.- to be the penon whose name is subscribed to this instrument as the attorney in fact of_ Fireman t s Fund Ins. Co <) _________ and acknowledaed 10 me thaitJ be 0 she subscribed the name of __J!,~,i.r.e.ma.n..'..,S._.1'J1RiL_L~_"-J:::9_'-________________lherelo as surety. and !if .. 0 .... own name as attorney in fact. IN WITNESS WHEREOF. I have hereunto set my hand and affixed my official seal. the day and year stated in this certificate above. :HQDU:-I-N " ;~-= n:' :;;~~-~;~: ~ '~:-:~~rf =~~1~ I'-~, h1.._." :Jl_,,~__~ , I,(:;Y ;.'- \. ., _, ,., .' '; I ':~ ."", 1'.OihRr FUbl.i_. , ~~'C,; ,.-,~ \\;;\~.;.!!;,:~r MER'::fO CCJNTY C~~:~Ot<'1'~'~ .' j \.~~. Me" E' _,_h '1"",',- ! '",,,~. 1 Grr.~:~'~~~;~:'....I_~~_} .w.w__._. /) -' ~ ~ ~ I 1.1 ~ ~ _____w_.w.~._ Notary Pubfic My commission expires ___,,!../~_...i.e.....9_"_____m."'''''.,''''.,'''__'''' SPECIAL PROVISIONS SECTION 1 SPECIFICATIONS AND PLANS 1-1.01 GENERAL The work embodied herein shall be done in accordance with the Standard Specifications for Public Works Construction, 1985 Edition, 1982 Edition of the Uniform Building Code and City of San Bernardino Standard Drawings, insofar as the same may apply and in accordance with the following Special Provisions. 1-1.02 DEFINITIONS Specifications the following understood to mean and refer to Whenever in terms are used, the following: the they Standard shall be Agency The City of San Bernardino Board The Mayor and Common Council for the City. of San Bernardino Engineer The Director of Public Works/City Engineer for the City of San Bernardino Inspector A Representative of the City of San Bernardino. Laboratory L A Wainscott & Associates, Inc. Notice Advertising for Bids Notice Inviting Bids Standard Specifications Standard Specifications for Public Works Construction, 1985 Edition, Uniform Building Code, 1982 Edition. Other terms appearing in the Standard Specifications, and these Special Provisions, shall have the intent ad meaning specified in Section 1-2, "Definitions," in the Standard Specifications. In case of these Special precedence over conflict between the Standard Specifications and Provisions, the Special Provisions shall take and be used in lieu of such conflicting portions. SPECIAL PROVISIONS 00800-1 342.04 ~ SECTION 2 2-1 PROPOSAL REQUIREMENTS AND CONDITIONS 2-1.01 GENERAL Bids must be submitted on the proposal form contained herein. All bids or proposals shall be signed, sealed and accompanied by cash, cashier's check, certified check or bid bond made payable to the City of San Bernardino, in the amount of ten percent (10%) of the bid. Such cash, check or bond shall be given as a guarantee that the bidder will enter into the contract, if awarded to him. In the event the bidder, to whom the contract is awarded, refuses to execute said contract, the use by the public of the improvements will be delayed and the public will suffer great damage. From the nature of the case, it would be extremely difficult and impractical to fix said amount of damage. Therefore, the City and the bidder agree that the proposal guarantee of 10% of the bid shall be said to the City upon the conditions set forth above as liquidated damages and not as a forfeiture. Bid bonds shall be underwritten by a surety company having a rating in Best's most recent Insurance Guide "A" or better. SECTION 3 3-1 AWARD AND EXECUTION OF CONTRACT 3-1.01 GENERAL Award of the contract will normally be made by the Mayor and Common Council at the subsequent Council Meeting after opening of the bids. The bidder, to whom the contract is awarded, shall file with the Engineer all required bonds and insurance policies, and execute the contract, within 5 calendar days after receiving notification of the award. Failure to file the stipulated documents and execute the contract within the prescribed time shall constitute good and sufficient grounds for recession of the ward and payment of 10% of the bid to the City as liquidated damages. 3-1.02 CONTRACT BONDS The Payment and Faithful Performance Bonds shall be filed with the Engineer before the contract is executed by the City in accordance with Section 2-4, "CONTRACT BONDS," of the Standard Specifications. SECTION 4 4-1, CONSTRUCTION SCHEDULE AND COMMENCEMENT OF WORK, TIME OF COMPLETION AND LIQUIDATED DAMAGES 4-1.01 Attention is directed to the provisions in Section 6-1, "Construction Schedule and Commencement of Work," in Section 6-7.1, "Time of Completion," and in Section 6-9, "Liquidated Damages," of the Standard Specifications and these special provisions. SPECIAL PROVISIONS 00800-2 342.041 _0"-- The Contractor shall diligently prosecute the work to completion before the 3rd Day of April 1987. The Contractor shall pay to the City of San Bernardino the sum of $500.00 per day, for each calendar days delay in finishing the work in excess of the date prescribed above. SECTION 5 5-1 LEGAL REQUIREMENTS 5-1.01 LIABILITY INSURANCE The Contractor's attention is directed to Section 703, "Liability Insurance," of the Standard Specifications, providing that the contractor shall furnish the City with a policy or certificate of liability insurance as prescribed therein, prior to execution of the contract. 5-1.02 WORKMEN'S COMPENSATION INSURANCE The Contractor's attention is directed to Section 7-4, "Workmen's Compensation Insurance," of the Standard Specifications, providing that the contractor shall file a signed certification Certificate of Workmen's Compensation Insurance before execution of the contract. 5-1.03 PAYMENT OF PREVAILING WAGE RATE The Contractor and all sub-contractors shall pay each craft or workmen employed on this project not less than the prevailing wage rates specified in Resolution No. 12846 of the Mayor and Common Council of the City of San Bernardino. The Engineer shall have the right to interview any craft or workman on the project site in order to verify payment of prevailing wage rates in accordance with Resolution No. 12846. 5-1.04 PAYROLL RECORDS The Contractor's attention is directed to the following provisions of Labor Code Section 1776 (Stats. 1978, Ch. 1249). The Contractor shall be responsible for the compliance with these provisions by his subcontractors. (a) The contractor and all subcontractors shall keep an accurate payroll record, showing the name, address, social security number, work classification, straight time and overtime hours worked each day and week, and the actual per diem wages paid to each journeyman, apprentice, worker, or other employee employed by him or her in connection with the public works. (b) The payroll be certified and reasonable hours at following basis: records enumerated under subdivision (a) shall shall be available for inspection at all the principal office of the contractor on the 1) A certified copy of an employee's payroll record shall be made available for inspection or furnished to such employee or his or her authorized representative on request. SPECIAL PROVISIONS 00800-3 342.041 Im':-T"^ (c) Each contractor shall file a certified copy of the records enumerated in subdivision (a) with the Engineer on a weekly basis. It will be the contractor's responsibility to submit the records enumerated in subdivision (a) for all of his subcontractors, in addition to his own employees. Failure to submit the records enumeraled in subdivision (a) on a timely basis shall constitute good and sufficient reason for withholding the partial payment for work accomplished. 5-1.05 BUILDERS RISK INSURANCE The Contractor shall secure and maintain in force a Builders Risk Insurance Policy in the amount of the contract price of all buildings that are included in the contract award during the life of his contract. A copy of the Builder's Risk Insurance shall be furnished to the City by the Contractor. The contractor will provide Builder's Risk "All Insurance, in an amount not less than the contract award naming the City and the consultant as additional insured. Risk" amountt SECTION 6 6-1 GENERAL 6-1.01 INCREASED OR DECREASED QUANTITIES If the total pay quantity of any item of work, subject to the provisions in Section 3-2.2.1, "Increased or Decreased Quantities," of the Standard Specifications varies by more than 25 percent, compensation payable to the Contractor will be determined in accordance with said Section 3-2.2.1 and these special provisions. When the compensation payable for the number of units of an item of work performed in excess of 125 percent of the Engineer's estimate is less than $1,500 at the applicable contract unit price, the Engineer reserves the right to make no adjustment in said price if he so elects, except that an adjustment will be made if requested in writing by the Contractor. Such Contractor's request shall be accompanied by adequate, detailed data to support costs of the item. Should the total pay quantity of any item of work required under the contract be less than 75 percent of the Engineer's Estimate therefore, the Engineer reserves the right to make no adjustment in said price if he so elects, except that an adjustment will be made if requested in writing by the Contractor. Such contractor's request shall be accompanied by adequate, detailed data to support costs of the item. 6-1.02 SOUND CONTROL REQUIREMENTS The Contractor shall comply with Chapter 8.54 of the City of San Bernardino Municipal Code regulating and prohibiting loud, unnecessary and excessive noises. SPECIAL PROVISIONS 00800-4 342.041 ~""'~=:.... Each internal combustion engine, used for any purpose on the job or related to the job, shall be equipped with a muffler of a type recommended by the manufacturer. No internal combustion engine shall be operated on the project without said muffler. Said noise level requirement shall apply to all equipment on the job or related to the job, including but not limited to trucks, transit mixers or transit equipment that mayor may not be owned by the Contractor. The use of loud sound signals shall be avoided in favor of light warnings except those required by safety laws for the protection of personnel. 6-1.03 LICENSE Business License from the execution of the contract. The Contractor shall obtain a City City of San Bernardino, prior to 6-1.04 EXTRA WORK Any extra work done shall conform to the provisions in Section 3-3, "Extra Work," of the Standard Specifications. However, equipment rental rates shall conform to State of California Business and Transportation Agency, Department of Transportation, Division of Construction, "LABOR SURCHARGE AND EQUIPMENT RENTAL RATES," latest Edition, unless the extra work is done for a negotiated price. Change order for extra work must be signed by the Contractor, Structural Engineer and approved by OSHA, City Council before extra work can commence. 6-1.05 HOURS OF LABOR In the event that the Engineer is required by the Contractor's operations to work more than eight (8) hours in any given day, or more than forty (40) hours in any given week, or on any Saturday, Sunday or Hol.iday, in the setting of Lines and Grades or performing inspections, the Contractor shall pay an amount to the City equal to one and a half (1 1/2) times the Engineer's normal wages and fringe benefits. Such amount shall be deducted from the next following progress payments. 6-1.06 PAYMENTS Attention is directed to Section 9-3, "Payments," and 9-3.2, "Partial and Final Payment," of the Standard Specifications and these Special Provisions. No partial payment will be made for any materials on hand which are furnished but not incorporated in the work. Final payment shall be made only after written acceptance of the work by the City Engineer. SPECIAL PROVISIONS 00800-5 '>.1. ') (V,, SECTION 13125 GRANDSTANDS AND BLEACHERS PART 1 - GENERAL RELATED DOCUMENTS: Drawings and general provisions of Contract, including General and Supplementary Conditions and Division 1 Specification Sections, apply to work of this section. DESCRIPTION OF WORK: GENERAL The work to be performed under this contract includes all labor, material and equipment necessary for the satisfactory installation of all items of work defined in the plans and specifications. The work consists of the following: 1. The fabrication and installation of three closed deck bleacher units. Section A behind home base to be 57 feet long, with 13 rows of chairs and two stair aisles with chair seats 18 inches wide. All aluminum frame understructure as shown on drawings. Vertical columns to be of 2" x 2" square tube, with all floor support members to be butt and lap welded to the square tube vertical columns. 2. One section on the first base side (Section B) and one section on the third base side (Section B') to be of the same general specifications except that they shall be 10 rows high and 49'- 10" long. Each section to have chair seats 18 inches wide. 3. There shall be Section C behind the first base dugout, and Section C' behind the third base dugout, as shown on layout drawing. These sections shall both be 10 rows high, 50 feet long, plank type seats with scalloped back rest and riser boards. 4. The fabrication and installation of 2 bleacher units (Section D and D') 51' long and 10 rows high, elevated, complete with aluminum frame understructure, square aluminum tube, all floor support members shall be butt and lap welded to the square tube vertical column. Reuse and modifications to existing bleacher seating to be utilized. 5. The modification, fabrication and installation of 2 bleacher units (Section E' and F') 72'-0" long and 45'-6" long and 10 rows high, elevated, complete with aluminum frame under structure, square aluminum tube, all floor support members shall be butt and lap welded to the square tube vertical column. Reuse and modifications to existing bleacher seating to be utilized. 342.04 Grandstands and Bleachers DESIGN AND WORKMANSHIP Units shall be of attractive design, free from objectionable projections and irregularities. They shall be first class workmanship with particular reference to smoothness of exposed bolts and nuts and freedom from all scratching, tearing, and pinching hazards. Design to be approved by owners. Product Data: Submit producer's or manufacturer's specifications and installation instructions for following products. Include laboratory test reports and other data to show compliance with specifications (including specified standards). o o o o Aluminum Stadium Chairs Plank Type Seating with Back Rests Elevated Bleachers Stairs Shop Drawings: Submit shop drawings prepared under supervision of a registered professional engineer, including complete details, calculations, and schedules for fabrication and assembly of seating and framing members, procedures, and diagrams. PART 2 - PRODUCTS MATERIALS: I. ALUMINUM STADIUM CHAIR EXTRUDED ALUMINUM: All aluminum parts of backs, seats, standards and seat arms shall be extruded aluminum, Alloy 6063- T6. No die cast parts will be acceptable. FINISH The chair should have an anodized finish with minimum guaranteed thickness of .0004 inches, conforming to Aluminum Association Standards AA-CZZA31, or a powder coat baked enamel finish of a color approved by the Engineer. BACK RESTS Backs shall be of three aluminum members, each member being 2 1/2" wide by 1/4" thick welded into an end channel to form a completed unitized seat. The members shall be properly spaced to provide adequate ventilation and free air movement. The seat numbers may be engraved in the top back rest member. All edges of the sitting surface shall be generously radiused and all corners shall be free of burrs and sharp edges. 342.04 Grandstands and Bleachers 1312,-2 SEATS Seats shall be of extruded aluminum of 2 1/2" x 1/4" members welded into end channels to form a completely unitized seat. The members shall be properly spaced to provide adequate ventilation. All edges at the seating surface shall be generously radiused and corners shall be free of burrs and sharp edges. CHAIR STANDARDS The chair standard includes the main support member, the armrest, the backrest support members, and the main hinge bracket. The main support member shall be 1 1/2" x 1 1/2" square tube. HINGES Hinges shall be designed so that it shall pivot on a swiveling and rotating one piece stainless steel bolt rotating in a sintered bronze bushing. The entire hinge assembly shall be impervious to moisture. The self-lifting function of the seat shall be accomplished with gravity as the only operating force. No springs or tentioning devices shall be used. The seat shall fold to a 3/4 position. II. PLANK TYPE SEATING WITH BACK RESTS: All materials are extruded aluminum alloy 6063-T6. No die cast parts are acceptable. FINISH The seat plank and backrest bracket shall have a silver anodized finish with minimum guaranteed thickness of .0004 inches, conforming to aluminum association standards AA-CZZA31. The backrest shall be anodized in either silver or gold, or painted with powder coat baked enamel in color or colors as approved by the Engineer. All existing bleachers shall be disassembled, modified as needed, then reassembled beyond Section C and C', in keeping with Engineers instructions. The design and fabrication of all bleachers complies in all respects with all applicable local and state ordinances, laws and regulations, and the Uniform Building Code. The Bleacher understructure is of aluminum, and is capable of supporting, in addition to their own weight, the uniformly distributed minimum unit live loads and forces: 100 Ibs, per square ft. of horizontal projection, seat and foot boards 120 342.04 Grandstands and Bleachers 13125-3 lbs, per lineal foot; sway forces applied to seat, 24 lbs per lineal ft. parallel to seats and 10 lbs. per lineal foot, perpendicular to seats; a wind load of 30 lbs. per square ft. of gross area of projected surface; and side and rear rails and guard rail posts shall be designed for a horizontal force of 50 lbs. per lineal ft. applied to the top railing. All mechanical equipment furnished complies with the California Administrative Code, Title 8 (Industrial Safety Orders), Title 24 (State Building Standards Low) and Title 17 (Public Health). III ELEVATED BLEACHERS Seat Plank: Seat planks shall be aluminum with a fluted, nonskid surface, be a nominal 2" x 10" or minimum 1.5" x 9.25" 6063-T6 alloy with silver anodized 204 R1 finish, conforming to Aluminum Association Architectural Standard AA-C22A31. Foot Plank: Foot planks shall be of aluminum with fluted, nonskid surface with minimum width of 18.5" of 6063-T6 alloy, mill finish. Hardware: Shall adequately connect seat and foot planks to the supporting structure so as to transmit all live and sway loads to the understructure members so placed to resist these loads specified. The connecting hardware shall be steel hot dipped or mechanical galvanized bolts and nuts, and aluminum clips. Open ends of seats and foot planks shall be covered with aluminum caps of matching finish, riveted to the planks. IV RAILINGS Guard Rails: Guard rails to be the eight rail system in keeping with 1985 Uniform Building Code. Top rail to be 42" above rear seat level. Chain link fence rail system will not be acceptable. Upon the approval and the award of the contract, the successful contractor shall submit three copies of working drawings and calculations for all structures including all railing details for review and acceptance prior to fabrication of bleachers. Guard railings along the sides and back of the bleachers shall extend 42" above the seat planks with open space between rails set so that a 6" sphere will not pass between. Side rail posts shall be of 2"x 2" x .125 aluminum capped with aluminum caps welded into place. 342.04 Grandstands and Bleachers 1~1~~ J Rear rail posts shall be of aluminum angle as required by design cales. All rails shall go through rail posts resulting in no unsightly "U" bolts or nuts protruding in seating area. Rail elbows shall be of aluminum and inserted minimum 4" into both rear and side rails. PART 3 - EXECUTION I. ALUMINUM STADIUM CHAIR: INSTALLATION SCOPE OF WORK: Installation is to be performed under the direction of a capable installation superintendent. This is to be done in a manner satisfactory to the Engineer. METHOD OF INSTALLATION: The seating plan is to be reproduced on the risers and/or treads, all dimensions checked against the plan and the necessary adjustments made in the layout for any discrepancies. RISER TYPE STANDARD: risers by means of two arranged vertically. Chairs shall be attached to aluminum 1/2" hot-dipped galvanized bolts II PLANK SEATING WITH BACKRESTS DESIGN Bench seating shall be designed to support a vertical load of 240 pounds per 18 inches of seating length without permanent deformation. Bench seating shall support 200 pounds per lineal foot supported on six foot centers with no more than 1/4 inch deflection between supports. Seats shall have a minimum wall thickness of .078 inches, and shall weigh no less than 1.90 pounds per lineal foot. Back rest shall be 1 extruded aluminum slat,S inches wide with 3/16 inch wall thickness. Backrest shall be furnished in sizes as required to insure proper aisle alignment in accordance with the plans. Backrest bracket shall be an aluminum channel 1.5 inches wide x .75 inches thick, bent to configuration as shown on attached drawing. CONSTRUCTION The seat plank shall be attached to existing supporting frames by using 4 way adjustable attachment clips with 1 5/8 inch long bolt slot for ease of installation. The backrest bracket shall be attached to the underside of the plank in the same manner. 342.04 Grandstands and Bleachers ,~,~~ ~ The backrest shall be attached to the backrest bracket adapter by using 1/4 inch "Prong less T Nuts." CONFIGURATION Bench seating shall be one piece extruded aluminum with a minimum width of 11.25 inches, with two internal legs. Seat surface shall have extruded serrations to prevent slippage and glare. Ends of aluminum planks shall be capped with an extruded aluminum end cap with a minimum wall thickness of .060 inches. III ELEVATED BLEACHERS BLEACHER DESIGN All equipment furnished shall comply with requirements of the Uniform Building Code; Title 24, State Building Standard, Title 17, Public Health and Safety; and the Uniform Fire Code. The understructure of each section shall be of aluminum and shall consist of a series of frames spaced at intervals no greater than 6' and joined by means of aluminum sway braces alloy 6061-T6 Each frame shall consist of vertical members, adequate diagonal braces and horizontal members of bearing on a level surface. The bleachers shall be designed to support, in addition to its own weight, a uniformity distributed live load of not less than 100 pounds per sq. foot. of gross horizontal projection of the bleachers. All seat and foot plank members shall be designed to support not less than 120 pounds per lineal foot. The bleachers shall be designed to resist, with or without live load, a horizontal wind load of 30 pounds per sq. ft. of gross vertical projection. They shall also be designed to resist in addition to the live load sway forces applied to the seats, in a direction parallel to the length of the seat plans, 24 pounds perpendicular to the direction of the seats, 10 pounds per lineal foot of seat plank. Railings shall withstand a loading of 50 pounds per lineal foot applied to top horizontal member making up the railing. Under the above loads stated, stresses in aluminum members and connections shall not exceed those specified for building type structures by the Aluminum Association. IV WARRANTIES Manufacturer shall provide a written 25 year warranty against all defects in materials. Installation contractor to provide a written 2 year warranty against defects in workmanship. 342.04 Grandstands and Bleachers 1~1~~ ~ AGREEMENT CITY OF SAN BERNARDINO This agreement, made and concluded this day of ,19 ,between the City of San Bernardino, the first pa~ and , party of the second part-:-------------------- party of Contractor, Article I - Witnesseth, that for and in consideration of the payments and agreements hereinafter mentioned, to be made and performed by the said party of the first part, and under the conditions expressed in the bond as deposited with the City, receipt of which is hereby acknowledged, said party of the second part agrees with the said party of the first part, at his own proper cost and expense in the Special Provisions to be furnished by said party of the first part, necessary to complete in good Workmanlike and substantial manner the BLEACHER ADDITIONS AND ALTERATIONS TO JOHN A. FI SCALINI FIELD AT PERRIS HILL PARK in strict conformity with Plans and Special Provisions No. 7150 and also in accordance with Standard Specifications for Public Works/Construction, 1985 Edition, City of San Bernardino, Department of Public Works/Engineering Division, on file in the Office of the City Engineer, which said Plans, Special Provisions, and Specifications, are hereby especially referred ~o and by such reference made a part hereof. Article II - And the said contractor agrees to receive and accept the following prices as full compensation for furnishing all materials and doing all work contemplated and embraced in this agreement; also for all loss or damage arising out of the nature of the work aforesaid or from any unforeseen difficulties or obstructions which may arise or be encountered in the prosecution of the work and for all risks of every description connected with the work; also for all expenses incurred by or in consequence of the suspension of discontinuance of work, and for well and faithfully completing the work and the whole thereof, in the manner and according to the Plans and Special Provisions, and requirements of the Engineer under them, to-wit: Article III - The said party of the first part hereby promises and agrees with the said contractor to employ, and does hereby employ the said contractor to provide the materials and to do the work according to the terms and conditions herein contained and referred to, for the prices aforesaid, and hereby contracts to pay the same at the time, in the manner, and upon the conditions above set forth: and the said parties for themselves, their heirs, executors, administrators, successors, and assigns, do hereby agree to the full performance of the covenants herein contained. . ' ITEM 1. 'JJ,"l nJ. BID SCHEDULE Additions and alterations of bleachers per plan and specs including materials and labor (concrete work not a part of this contract) Lump Sum Q $ 221. O()(). - . PROPOSAL 00300-2 '-" . Article IV - It is further expressly agreed by and between the parties hereto that should there be any conflict between the terms of this instrument and the bid or proposal of said Contractor, then this instrument shall control and nothing herein shall be considered as an acceptance of the said terms of said proposal conflicting herewith. Article V - Execution and Amendments. This agreement and any amendments or modifications thereto shall not take effect or become operative until fully signed and executed by the parties and no party shall be obligated hereunder until the time of such full execution. No oral agreements, amendments, modifications or waivers or intended or authorized and shall not be implied from any act or course of conduct of any party. IN WITNESS WHEREOF, the parties to these present have hereunto set their hands the year and the date first above written. ATTEST: ::4ii~ ~/?.-?/~~ SHA~A CLARK, City Clerk Approved as to form: CONTRACTOR Name of Firm: WJCKUM CONSTRlJCTION .389 W. aLloTT B~;?-~/juX- TI TL E : ELTON J. W1ClWM (PM1lti8I MAILING ADDRESS: WICKUM CONSTRlJCTION 4389 W ElLIon MERC'.ED, CAll'. Olue City Attorney 2aC( PHONE NO~(7H) ???--~ J.>21:, B,nder No 4587 LORENZI-MASASSO AGENCY. INC. 1901 G ST.. P.O. BOX 2009 MERCED, CA 95344 TEL: (2091 383-0220 Effective 12:01 am 1-26,19 87 Expires 0 12:01 am 0 Noon 2-26 ,19 87 o This binder IS Issued to extend coverage In the above named company per expiring policy "# (eKepl i1S noted belowl Description of Operation/Vehicles/Property NAME AND MAILING ADDRESS OF INSuRED Elton Wickum & Sanford Wickum a partnership DBA: Wickum Construction Builders Risk Type and Location of Property Coverage/Perils/Forms Am! of Insurlnce Ded. ...... " Parris Hill Park "All Risk" Corner of Harrison St., & Highland Ave. San Bernardino $229,000 ,000 100 if .':;'j1 ., "", 'S CQ"ral'(E~ " .' .,.' Limits of Li.bir Eoch Occurrence I Type of Insurance \ D Scheduled Form ~ Premises/Operations ~ Products/Completed Operations ~ Contractual o Other (specify below) D Med. Pay. $ [):Personal Injury D Comprehensive Forni\, DC odlly InjUry $ Property Damage $ Bodily InjUry & Property Damage Com ined 1 000 Personal InjUry Limits of Li.bili Bodily Injury (Each Person) Bodily Injury (Each Accident) $ ....., $ Po< Person $ Po< Accident DA OB 1,000, $1,000, ~Llablllty ~ Non,owned o Comprehensive. Deductible o Colllsion.Deductlble atMedlcal Payments CJ:Unmsured MotOrist o No Fault (specify): o Other (specify): GF Hired $ $ $ 1,000 $ 1,000,000 $ $ Property Damage $ Bodily Injury & Property Damage Combined $1,000,000 o WORKERS' COMPENSATION - Statutory limits (specify states below) D EMPLOYERS' LIABILITY - Limit SPECIAL CONDITIONS/OTHER COVERAGES Bleacher addition and alteration to the field, Parris Hill Park, San Bernardino NAME AND ADDRESS OF D MORTGAGEE D LOSS PAYEE ADD'L INSURED City of San Bernardino LOAN NUMBER at ACORD 75 (11.77) :3inder No 4589 LORENZI-MA5A550 AGENCY, INC. 1901 G ST.. P.O. BOX 2009 MERCED, CA 95344 TEL: (209) 383-0220 Fund Effective 12: 01 a m 2-26, 19 87 Expires 0 1201 am 0 Noon 3-26 ,19 87 o This binder IS Issued to extend coverage in the above named company per expiring policy # (except CIS noted below! Description of Operation/Vehicles/Property NAME AND MAILING ADDRE.SS OF I~SURED Elton Wickum & Sanford Wickum a partnership DBA: Wickum Construction Builders Risk Type and location of Property Ami of Insurlnce Ded. Caino. " Coverage/Perils/Forms Parris Hill Park Corner of Harrison St., & Highland Ave., San Bernardino "All Risk" $229,000 5,00 100 Type of Insurance limits of liabill Each Occurrence Bodily Injury $ Property Damage $ Bodily Injury & Property Damage Comb," 1 000, Personal Injury limits of liabili odily Injury (Each Person) odily Injury (Each Accident) $ $ Coverage/Forms te o Scheduled Form l<l Premises/Operations l<l Products/Completed Operations 1fI Contractual o Other (specify below) o Med. Pay. $ ItJ Personal Injury o Comprehensive Form $ $ p" Accident 1,000, $ 1,000, p" Person $ m liability m Non-owned o Comprehensive-Deductible o Collision-Deductible IKI Medical Payments KJ Uninsured Motorist o No Fault (specify) o Other (specify) !9 Hired $ $ $ 1,000 $ 1,000,000 Property Damage $ Bodily Injury & Property Damage Combined $ 1,000,000 o WORKERS' COMPENSATION - Statutory limits (specify states below) o EMPLOYERS' liABiliTY - Limit $ 2,000,000 SPECIAL CONDITIONS/OTHER COVERAGES Bleacher addition and alteration to the field, Parris Hill Park, San Bernardino NAME AND ADDRESS OF 0 MORTGAGEE 0 LOSS PAYEE iI ADDL INSURED City of San Bernardino LOAN NUMBER ~ ~~..L:.2~~ Signature of Au rized Represe y Da ACORD 75 (11-77) Lorenzi-Masasso Agency, Inco 1901 G Street P.O. Box 2009 Merced, Ca. 95344 COMPANIES AFFORDING COVERAGES COMPANY A Fireman's LETTER Fund COMPANY B lFr1fR Fireman's Fund COMPANY C LETTER Fireman's Fund COMPANY D ,-EITER COMPAN)' E LETTER NAMf AND ADDRFSS OF INSURED COMPII.NY LETTER Elton Wickum Etal Wickum Construction 4389 West Elliott Merced, Ca. 95340 This is to certify that policies of insurance listed below have been issued to the Insured named above and are in force at this time. Notwithstanding any, requirement, term or c )ndition of any contract or other document With respect to which thiS certIficate may be ISSUed or may pertain. the Insurance afforded by the poliCies deSCribed herein 1$ subject L all the terms. exclusions and conditions of such policies TYPE OF INSURANCE POLICY EXpIRATION DArE Limits of Liability in Thousan s ( OCC~~~~NCE AGGREGATE POLICy NL;MBER A GENERAL LIABILITY tI COMPREHENSIVE FORM f] PREMISES --OPERATIONS EXPLOSION AND COLLAPSE rlAZARD UNDERGROUND HAZARD PRODUCTS COMPLETED OPERATIONS HAlARD CONTRACTUAL INSURANCE BROAD FORM PROPERTY DAMAGE INDEPENDENT ,:ONTRACTORS '1,000 ' 1,000 BODIL Y INJURY , , TBD 1/1/88 PROPERTY DAMAGE , , BODlL Y INJURY AND PROPERTY DAMAGE COMBINED PERSONAL ;NJURY PERSONAL INJURY , I, 000 B i AUTOMOBILE LIABILITY ~ :::::E~ENS'VE 'ORM 1tJ NON.OWNED I 1/1/88 BODILY INJURY , (EACH PERSON) BODILY INJURY , (EACH ACCIDENT) PROPERTY DAMAGE , BODILY INJURY AND PROPERTY DAMAGE '1,000 COMBINED BODIL Y INJURY AND PROPERTY DAMAGE , COMBINED III TBD EXCESS LIABILITY ')MBRELLA FORM OTHER THAN UMBREL~A FOPM C 'WORKERS' COMPENSATION and EMPLOYERS'lIABILlTY OTHER STATUTORY WP80104947 7/1/87 - '2 000 OQQ.cmw DESCRIPTiON OF QPERATIONS/LOCATIONSNEHIClES Bleacher Addition and Alteration to the Field, Parris Hill Park, San Bernadino City of San Bernadino is Named as Additional Insured Cancellation: Should any of the above desc3lBed pOliCIes be cancelled before the expiration date thereof. the iSSUing com- pany will eJrk1tJetXEXmail _ days written notice to the below named certificate holder. but failure to mail such notice shall impose no obligation or liability of any kind upon the company. NAME AND ADDRESS OF CERTIFICATE HOLDER January 26,1987 City of San Bernadino GATE ISSUED: AUTHORIZED REPRESENTATIVE Lorenzi Masasso Agency, Inc. P.O. Box 2009 Merced, CA 95344 THIS CERTIFICATE IS ISSUED AS A MATTER OF INfORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AMEND, EXTEND OR Al TEA THE COVERAGE AFFORDED BY THE POLICIES BELOW. COMPANIES AFFORDING COVERAGE INSURED COMPANY A Fireman's LETTER Fund COMPANY B LETTER Fireman's Fund COMPANY C I LETTER Fireman's Fund I COMPANY D ! LETTER I COMPANY E i LETIEA I Elton Wickum Etal Wickum Construction 4389 WEst Elliott Merced, CA 95340 THIS IS TO CERTIFY THAT POLICIES OF INSURANCE USTEC BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFlCATE.MAY IE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POUCIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS, AND COND. TIONS OF SUCH POLICIES. . TYPE OF INSURANCE POLICY NUMBER POLICY EFfECTIVE POliCY EXPIRATION LIABILITY LIMITS IN THOUSANDS DATE {MWOOiYV} DATE(MM;t)()I'('(l H AGGREGATE OCCURRENCE BODILY 1-1-87 1-1-88 INJURY $ $ PROPERTY DAMAGE $ $ 81' PO $1,000, $1,000, COMBINED PERSONAL INJURY $1,000 _v ....., $ (~FlPEml 1-1-87 1-1-88 _v If"'" {PEFl.l,COOENTI $ PROPERTY DAMAGE $ BI & PO I COMBINED $1,000 BI&PO 1$ $ i COMBINeD 7-1-86 i 7-1-87 $ 2 OO(J;i'OO\1IC'OEND $ IOISEASE-POllCY UMID I $ IDISEASE-EACH EMPlOYE~l I COMPflfHENSIVE FORM PflfMlSESIOPERA TlONS UNllERGROUND EXPlOSION & COllAPSE HAZARD PROOUCTSICOMPlffiD OPERATIONS CONTRACTUAL INDEPENDENT CONTRACTORS BROAD FORM PROf'ERTY DAMAGE PEASDNAL INJURY TBD AUTOMOBILE LIABILITY ANY AUTO ALL OWNED AUTOS (PRIV PASS) ALL OWNED AUTOS (OTHER THAN. ) PRIV, PASS HIRED AUTOS NON-DWNEO AUTOS GARAGE LIABILITY TBD EXCESS LIABlUTY UMBRELLA FOAM OTHER THAN UMBRELLA FORM WORKERS' COMPENSATION AND EMPLOYERS' UABIUTY WP80104947 OTHER DESCRIPTION OF OPEAATIONS/LQCATlONSNEHICLES/SPECIAL ITEMS Bleacher Addition and Alteration to the Field, Parris Hill Park, San Bernardino Additional Insured PERFORMANCE BOND Bond No. C- 6452386 cA FIREMANS FUND DIII..IEI ........ FIREMAN'S FUND INSURANCE COMPANY THE AMERICAN INSURANCE COMPANY NATIONAL SURETY CORPORATION ASSOCIATED INDEMNITY CORPORATION AMERICAN AUTOMOBILE INSURANCE COMPANY The premium for this bond is $ ::l?AA. no payable in advance and subject to adjust- ment at current manual rates. as Princiw~ an~ 01 Calir. Fireman's Fund Wickum Construction 4389 West Elliott Ave. Merced, Ca. 95340 Ins ur a nee Comp an y ,a corporation organized under the laws of the Calif. State KNOW ALL MEN BY THESE PRESENTS: That we, and duly authorized under the laws of the State of to become sole surety on bonds and under- taking, as Surety, are held and firmly bound unto City of San Bernadino as Obligee in the full and just sum of Two Hu d d Tw tN' Th d n re en y 1ne ousan ---_________________________ Dollars, ($ 229,000.00). lawful money of the United States of America, to be paid to the said Obligee, successors or assigns; for which payment, well and truly to be made, we bind ourselves, our heirs, executors, successors, administrators and assigns, jointly and severally, firmly by these presents.' The Condition of the above Obligation is such that whereas the the said Obligee to do and perform the following work, to-wit: said Principal has entered into a contract of even date herewith with Bleacher Addition and Alteration to the Field, Parris Hill Park San Bernadino > as is more specifically set forth in said contract, to which contract reference is hereby made; AITORNEY IN FACT ACKNOWLEDGMENT STATE OF CALIFOIINJA COOIIItJoI MerCea On this _ 26th Merced .._...._.~.._._._...._._....Mm...M.......... ..County, State of Cali fomi a, residing therein, duly commissioned and sworn, personally appeared Joseph A. Proietti ----__._._.___.__.___~.... -.oIly........."'_. 0 ........"'_...1Ioo_0I................c:.- to be the penon whose name is subscribed to this instrument as the attorney in r""t or _F i .reman's 'un dIns uran ce omp an y and ""kDowledied to _ that ~.. 0 ... subscribed the name of _.___J oseph A. Pro i et !.l---____________thereto as surety, ancI i!!i ... 0 .... own name as attorney in f""t. .' IN WITNESS WHEREOF, I have hereunto set my hand and affixed my official~ ,eal, 1~!.lIeard' certificate above. ~' STARRE J. WELLS~~ - /~#-/-. _________._____ I NOTARY PUBLIC ..-J Notary Public . MERCED COUNTY, CAU~IA .. . / ~~/ ~// My con",.:AiDA Expires AprIl. 1911 My comnusslon expires _..:__ (-, January . 1987 day of __._.__._.........._M._............. ................ In the year ......_._....__......._.~._ ........_._...._...._....... before me. a Notary Public in and for said -.- PAYMENT BOND-PUBUC WORKS Bond No. C- 6452386 c4 FIREMANS FUND .........u........ FI"I!:MAN'. I"UND tNSUIIlANCI!: COMP....NY THE: AMI!:IIlICAN INSURANCE COMPANY NATIONAL SURETY CO"POIU.TlON .....OCI...TED INDEMNITY COR,oolllATION AMIl't1CAN AUTOMOB'LI!: INSU"ANCIE COMPANY HOME OFFICE: SAN "''''''NetSeO, CALIFORNIA KNOW All MEN BY THESE PRESENTS: That we, Wickum Construction-4389 West Elliott Ave. Merced as Principal. and Fireman's Fund Insurance Co. , incorporated under the law. of the State of Cali f. and authorized to execute bonds and undertakings as sole surety, as Surety, are held and firmly bound unto any and aU persons named in California Civil Code Section 3181 whose claim has not been paid by the contractor. company or corporation, in the aggregate wtmm Two Hundred Twenty Nine Thousand-------------------------------------- Dollar., (. 229, 000.00 l, for the payment whereof, well and truly to be made, said Principal and Surety bind themselves, their heirs, administrators, successors and assigns. jointly and severally, firmly by these presents. The Condition of the foregoing obhgation is such thatj whereas the above bounden Principal has entered into a contract, dated January 19 . 1987, with the Wickum Construction to do the following wort, to-wit: Bleacher Addition and Al tera t ion to the Field, Parris Hill Park, San Bernadino Now, Therefore, if the above bounden Principal, contractor, person, company or corporation, or his or its sub-contractor, fails to pay any claimant named in Section 3181 of the Civil Code of the State of California, or amounts due under the Unemployment Insurance Code, with respect to work or labor performed by any such claimant, that, the Surety on this bond will pay the same, in an amount not exceeding the aggregate sum specified in this bond, and also, in case suit is brought up.:ln this bond, a reasoncLJle attorney's fee, which shall be awarded by the court to the prevailing party in said suit, said attorney's fee to be taxed as costs in said suit. This bond shall inure to the benefit of any person named in Section 3181 of the Civil Code of the State of California so as to give a right of action to them or their assignees in any suit brought upon this bond. A1TORNEY IN FACI' ACKNOWLEDGMENT STATE Of CALIFOIlNIA I .0 CMatyof MerCea l On this ____.26 t h _.__...__dsy of .if~_I!~.aI:y..__........._........ in the year .....!.!:l. 8 7 .....__.._._____, before me, a Notsry Puhlic in and for said Merced C t S fC I'" 'd' h . d I . . 'H___.~_ - " ~._~..H.H...._..H_.........~..._ oun y, tate 0 a nomla, res. Ing t ereln, u y commissioned and sworn, personally appeared Joseph A. Pr01ett1 ________~.... _.">'_to-.Oprl!ftd"__lIIe_of~_ to be the person who.. name issubscribed tothi. instrument as the attnmey in fact of Fir_eman' s Fund Insurance Co .___ and acknowledpd to me that ES 1000" subscribed the name of _ Joseph A. proietti _thereto.s surely. and ~ ... 0 .... own name as attorney in fact. IN WITNESS WHEREOF, I have hereunto set my band and affixed my offi. cial seal, the day and year s artd in this_ +te above. , W-~r STARRE J. WELLS NOTARY PUBLIC MERtED COUNlY, CAURlIlNIA '..' ~ ~'~y CJ7n:r.~;on Ex;tires April 1. 1 _ u___. ___ ".~...~.-- '::> Notary Public / ~ /)'/1"" My commission expires ~_1__ (;F.NERAI. rOWER ot' ATTORNt:'I' FIREMAN'S FUND JNSURANCE COMPANY , KNOW AI.L MEN B\' TIIt~~t: rREst:NTS, Th:l' FIREMAN'S Fl'ND INSURANCE COMPANY,:I C"'l'ora';on duly or~an;,.d and pisling und.. ,h. law\ of Iht Slale of Californhl. :md hil\'inf it!". rrincipal'offit:t in Ihe Cil}' and COllnl~'l1f S.1n Frant:i!".(u, in said 51;11e. ha" mude, con!".tituled and 3'1"'f'oinletl. and duL''' ")' 1he.\.c rrc"cnts make, con!itllutc and ;'"'rruint JOSEPH A.PROIETTI. ALBERT DIBBLEE and ELMER J; LORENZI jointly or severally , iu Irue and lawful AllornC'y(~)-in-Facl. wilh full power and authority hereby confentd in its name. pl:lce and 'tead. 10 eltecule. seal. acknowledge and deliver an)' and all bond!i. underlakin,!', recolnil~nce5 or olher wrillen obliBalions in Ihe ",lIure Ihereof --------------------------- and to hind the Corroflllion Ihereh}':.IS fully and 10 the 'a me e,lenl ,,!". if such honds were !"oignC'd hy lhe Presiden!. sealed wilh lhe corrorale "ea1 of the Corroralion and duly attesled hy its Secretary. htrehy ratifying and confirming alllhallhe !".aid A1IorneyCs)-in-Filcl may do in the premise", This rl,werof allOrne) is granted puuuant 10 Article VIII. S~ction ~O and ~I of U),.la.....~ of FIREMAN'S FUND INSURANCE COMPANY now in full force and cffecl, . ".'\nide '.111. ..\1'('oi",I1I('1II and AUlhorit.l' .4.ui"a"'~~a('l;Jri<,.(, :Jluf Alllun('y.in-/-";Jo .1J1(} Apt''''\ III al'l't'(" 1,<'J:al }"lIl'('U alld MaAt' ..\ppt'.1ra/Kt'). SC..:liUI1 .10. .'\Plwimmt'lII. The Chairman of Ihe Uoart.l"r Dirc"..:lur\. Ihe Prt'\it.lclIl. an~ Vkt'-Pf('\idc.'fll or allY t'lhcr pcr~on aUlhori/et.l by lhe Board of Diredtlr',. Ihe Chairman of Ihe Uoard or Dire":lor!'>. Ihe IJrc\idclll or allY \'i..:c-Pre~idcnt. may. from lime 10 lime. arpoinl Rc~it.lelll .'\~~i\la1l1 Sc.'nelaric_~ anJ Allorneys.jn.FuCl 10 rerrc\enl and ael for and on hehalf of Ihe Corrtn.lIion and ,o\g.(,lll\ 10 a..:"'crl le!,al pwees\ and male nppear;lIlees for and 011 behalf or Ihe Corrurlllion, Sec.'lioll .11. ..tull1t)ri,y. Tht' ..'uthoril)" of ,ueh Rc,jdt'nl A\,i,l:lIll St'..:relarit", ^llurllt'~\-ill''''I'':I. and ^~l."llb ,hall hI." ii' l'Hc\..:tibrd in Ihc in\!rUOll'nl e\ idcneil1~ Iheir arpOinlmel1l. and allY such nppoinlnlenl and all aUlhorilY gran led lheret'ly m"~ l1c rt'\ iled :II an~ lime 11~ the Uoard of Dire..:!o" 01 11~ an~ f1er,(In enlpo\\ered 10 male meh arroinlmclIl:" Thi!ii rower of "Horne)' i~ "il!ned and ~e.\Ied under and t-.y the aUlhorily of the followin~ Re...olulion adorled hy the I1nard of Direclors of FIREMl\N'S FUND INSURANCE COMPANY al a meelinl! dul)' called :lnd held on the t~lh dilY of Jul)', ItJblJ. <lnd ...aid Resolution has nol heen :m~ended or rtpeuled: "RESOL VED, thilt the signature of any Vice-President, A!'isislant Secrclary. .md Residenl Assistant Sccrerar~' of Ihis Corporation. and lhe seal of Ihis Corporalion may he affixed or printcd on an~' rower of altornq. on any revucalion of any ruwer of aHorney. or on any cenilicale relalin[t thereto, \1y fac!liimile, and an)' power of allorney. .an)' rnoc:llion of ilny rowtr uf allmnC')". or certificate \1earin(!. ,uch facsimile "ignalure or facsimile seal ~hall he \<'alid imd binding IIJ1\m Ihc Corror"'ion," , IN WITNESS WHEREOF, FIREMAN'S FUND INSURANCE COMI'ANY ha, .all'td Ih.,c I',.,.nl' '" h. ,i~ned hy jos Vicc.Prcsid.nl. and in (or para Ie scalia be hereullIo affixcd Ihh 2nd da~ of Februarv ,19~ FIREMAN'S FUND INSlIRANCE COMPANY l,c)'~w,4-~ II) Vio:t.I'It~'Hkn' in A TE OF CALIFORNIA. CIT\' ,\ND COUNTY OF SAN FRANCISCO } ", O",hil 2nd d.,llf Februar.l' , 19 _~, bdllr.m.l'mlll1:1I1\'c.mc _~.!.!llam W. Lauber , 10 me lno\\n, \\ho, being b)' tT1t' duly "worn, did dcrO\C <IIld \ay: fhal hC' is \'ke-Pre~idelll of nR[~Il\N.S rUND INSURANCE CO:\IPANY, Ihe Cor. rOflJlion described in a.,d which t'~eculed Iht' al1o\-e imlrumcnf: Ihal he lnow\; Ihe seal of ,aid Corl1or;Jlioll; Ihal Ihe se,,1 affixed 10 Ihe ~aid irmrUlllt'nl is such corporate ~eal; that il wa\...o affixed by orde~ of the Uoard or Uirl.'ctors of s,lid COlporalion and Ihal hc ~i~lled hi, name Iherelo by lile order. IN WITNESS WHEREOF, I have hereunlo ..el my hand and affi.\cd my officinl \eal, the day and year herein finl above wrillen. .I"I'IIIIIIIUIUUI'IIIIIH'UIIIIIIIIIIIIIIIIIII"IIII. P OFFICIAL SEAL e e ei)ei)'i< SUSIE K. GILBERT e i ",- . - ,; HOT ARY PlI8l1C . CAlIFORNIA 5 :'. ~ all & COUNTY OF SAIl fllAIl(ISCO e' : ' My Commission hpires Nov, 1" 196.4 '1 IIIIIIII...II......III.."I..IIIII.IIII.U............., . ' /~~~~ ....\.I:Il\I'ut>ho: n:RTIt"ICATt: STATE OF CALIFORNIA. CITY ,\NII COl'NT\' OF SAN t'RANClSCO } ", I, Ihe ulldersiJned, Rt'!".idellt A~~i"lanl SeC'rC'lar~' of 1:1REMAN'S J:UND INSURANCE COMPANY, a CALIFORNIA Corroral;on, DO UfRUJY CERTIFY Ihal Ihe fore,oinl,! and all ached 1'0\\ ER or AT rORNEY rC'maill' in full foret' and hilS nOI been re\'oled: rtnd furthermore lh.11 Ankle \' III. St'C!iom 30 and 31 of Ihe ny-Ia\\"~ of Ihe Coq;malioll, and Ihe Re!'>olulioll of Ihe Uoard of I>ircclor.., ~CI forth in IhC' Power of AlIornt')', :Irc 110\\ in force. 26th day of January 87 ,19_, Si,ned and ,ealt'd allhe City and CounlY of San hanci!il:o. Daled the ___tt ...t....&II ~P:'~':.9"'; ~~!n ., . "'~ , 1'\'tl"'" -. ,4 lia Rr,idC'nl ""j\lllln' S'....'C'I:"~ ~ (IEN,ERA!. , 'I"I'! 1 'I :',.' ~rrJ~N~{ Ii;" ;iI' II ! 'I 'i' FI~EMAN'S FUNDJNSURANCE COMPANY " ~NOW ALL MEN B\' THFA~E PRF.~ENTS, ,'f1la\ FIREMAN'S FUND INSURANCE COMPANY, II Co,,,,,,a'ion duly o'ganized and ..i"ing unde, ,he 13i"'~ ur IK~ Stalt of California..and havinp.lts principal ornee in Iht.'City and COUn1)' tlf San Francisco, in uid Slate. hi! made. constituted and appointcd. ind dots- by thc!l~ rrurnHi make. (,-'osllrute ~nd RJ'lf'C.ti"1 . I "'" ,- ',' I ,I': JOSEPH A. PROIETTI, ALBERT DIBBLEE and ELMER J. LORENZI ," " jointly or severally -, its true and lawful AltornC'y(s)-in-Fact. with full power and nuthorily hercby conferred in its "a'me. plllce and slead. to tueule. seal. acknowledlEc and drlivC't any and aU N.mds.untlerulkinll!l. rcco,nilnnct!li or olherwrillcn ohh"ulitlRS in the nlllure- Ihcrco.r .-------------------------- and 10 bind the Corporation thereby as rully and 10 Ihe !liame Ulent a!li ir l'uch honds were l'ianed hy the Presidenl. sraled with the corporale !liral or Ihe Corporation and duly.auesled by its Secretary. hereby ratifyin, and confirminl all thai the said AuorneyCs)-in-Fact may do in the premises.' 111i. powe, of a"ornh i. g,an,ed punuanllo A"ide VIII, Seclion JO and)1 of By,law. of FIREMAN'S FUND INSURANCE COMPANY now in filII force and effeCl, , .', ' -. . "Ankle VIII. Appoillfm~nt and .o\u,hori,... Aj~;.\lant .~ec:'t'arie$. alld ..tllornty-in,':a.." and AG('n,-~,o a"'~'tp,-itGal "ffh.'t~.~ :Jnd AlaAe' Appraranccs, Seclion 30. AI',,()illlmrn~, The Chairman or Ihe Board or Director... the "re..iden!. an)' Vice.Pre\idt'nt or an)' other l'C'rson aUlhorilcd b)' Ihe Board of Dirtl:lor... tht Chairman or the Board or D1rcclon. the Prellidel1l or an)' Vkt.Pre~idenl. may, rrom lime 10 linu~. al'POinl Resident A\'loi!.lanl Sl.'l:relilrie~ and AlIorne)"~.in.Fal:1 10 ~e"re\enl and ael ror,and on behaU or lhe Corroration and ,l\~enh to aece!," le,al proces\ and mal.e appearances ror and 011 behalf or Ihe ('orporalion, < I' i . Sel,:tion 31. ..\mht1ri,y. The "'IHhmil)' or \Ul:h R,..idenl As..hlanl SC(rct3ric',. Allorne)...in....acl. and ^#...I1!\ ..hall he ali rne..crihed in Ihe i"'lrulllcnl e\ idcndnl: Iheir arroinlmenl. and any liuch appoinlmenl and all aUlhoril)' ,ranled thercb)' ma~' be re\-il.cd al an) linu~ h) th... Uoard or Oireclor.. or by an)' pcr!Oon empo\\ ered 10 mal;t ~uch apl"oinlmcnr." Thi!l rowtr of attorney i!' ,il!ned and sealed under and by the-authorilY or Ihe rollowinfC Re!lolution adorled by the Hoard or Direclors of FIREMAN'S FUND INSURANCE COMI'ANY al a mee'ing duly called and held on Ihe 1~lh day of July, 1%6, and ..id Re.olution has no' heen amendcd or re"ealed: "RESOLVED. that the signalUre of any Vice.Ptesidenl. Assistant Secretary, and Resident Assistanl Secretar)' of this Corporation. and the seal uf lhi~ Corporaliun may he aftbed or printed on an)' row~r of attorne). on an~' rrvocation of ,any power ,of attorney. ~r ,on ~ny certificate r~la!ing thereto. ~~' fac!'iimile.:and any rower of Iltorney. anr. rt\"ocallon of any power of allorne)'. or ceTlllicate hearlnl !liuch faCSimile slenalure or faCSimile seal shall tie 1"alid and binding UptlO the Corporal ion. " . IN WITNESS WHEREOF, FIREMAN'S FUND INSURANCE COMPANY has ca".ed ,hue ",e..nl. 10 he signed by i.. Vice,p,..idenl. and itHo,,,o,a,,,c.I,o bc hmunlo arfhcd ,his 2nd dB, of Februarv , 19 ~ ' FIREMAN'S FUND INSURANCE COMPANY Lo'~ W, ~~ 0) VM:t',Prt'~idul SH TE OF CALIFORNIA, fiT\' ANIl COUNT\' OF SAN .'R.~NCISCO } ,., On ,hi, 2nd dayor February , 19 ~,bofo,cme"mon.llycaOlc William W. Lauber , ,10 me kno\\n. who. being h mt duly S'A'orn. did depo\e and ..ay: Ihal he i!i Vice.Pre!liden1 or F1RE~IAN'S fUND INSURANCE COMPANY. Ihe Cor. poration dC'!lcribed in ,and which executed Ihe aho'ic in!ltrun1cnt: Ihat he knowl; Ihe ~eal (II' !Oaid Corporal ion: Ihal the !ieal aHixed 10 the said instrument : is such corporale !loeal; thai il wall so aUhed b). order or Ihe Soard or Direclors or ~aid Corporalion and Ihal he !ii~ned hi!' n3me thereto b)' li~e order. IN WITNESS WHEREOF, I have hc'Tt'unlo \tl m)' hand and aHixed m)' official seal, the day and year herein first abo\"e wriflen, ....II.,.II..IIIt.Il"""",....II.........II........'"... ! OFFICIAL SEAL i! - e)-'~ SUSIE K, GILBERT I I -,' . ,; NOTARY MlIC . CAUFORNll _ ',- all & COlIN" Of SAIl _CISCO I : . My Commission hpires No.... 17, 198. i..IIII.IIIII.,IIIII........II....HIII........... rzt-~: J;~'~.z.~ !'\h'lilryl'uNII: ('ERTlnCAn: STATE OF CALIFORNIA, CIT\' ANIl Cot'NT\' OF SAN FRANCISCO l .I ~., " I. ,he undcrsi,n.d, Re.idcnl A"imnl SocrCIB'y of I'IREMAN'S FUND INSURANCE COMPAN\', a CALIFORNIA Corro,alion, DO HERIIl\' CERTIFY Ihallhe fore,oin, and I!lached POWER 0.." ATTORNEY rtmain!O in rull rOrCf and hU!li nol been revoked; and rurlhermorr Ih31 Ankle ""'. Seclions 30 and 31 or Ihe 8)'.la\\'~ or Ihe Corporal ion, and Ihe Re!loolulion of the Board of Direclon. set fonh in the Power of Altorn!:)', are 110\\ in rorce. 26th Si,ned and ~t'lled at the Cily and CounlY or San Francisco. Daled the da,'of January , 19 .J!L ' Ida ,Rf'oid,:nl A....i~l.nl S..'\:'CIIU) ~ J....__~~ .._ ..... .... ~,;;.~:,~" ";' ; "'~'- " <, \. d . ! . . I' ~. "_\'1(" ,4 I,' FT'.n" "