HomeMy WebLinkAbout24-Public Works
CITy .OF SAN BER.RDINO -
REQUEST .R COUNCIL ACTION
File No. 6.14-97
From:
ROGER G. HARDGRAVE
Subject:
Authorization to Execute Agreement
for Professional Engineering Design
Services - Security Lighting in
Perris Hill, Wildwood, Lytle
Creek, Nicholson Parks
---BSI CONSULTANTS, INC.
Dept:
Public Works/Engineering
Date:
1-16-92
Synopsis of Previous Council action:
July, 1989 -- Approval of $161,000 in 1989/90 Park Construction
Fund Budget, under Acct. No. 243-363-57608,
approved.
July, 1990 -- Approval of additional $39,000 approved as
supplemental funds, in 1990/91 Park Construction
Fund Budget.
Recommended motion:
Adopt resolution.
cc: Shauna Clark
Andy Green
Annie Ramos
Jim Penman
w
Contact person:
Gene R. Klatt
Staff Report,
Aareement. Resolution
Phone:
5125
Supporting data attached:
Ward: 2. 1. and 4
FUNDING REQUIREMENTS:
Amount: $20,5RO 00 (P~r~ Construction Fee Fund)
Source: (Acct. No.!
243-363-57608
Acct.Oescri tion Rehabilita
Securit
-IJ~
at wildwood. Perris Hill. Lytle Creek
and Nicholson Park
Council Notes:
Finance:
75~0262
Agenda Item No
;21
CITY OF SAN BER~DINO - REQUEST eR COUNCIL ACTION
STAFF REPORT
In September of 1991, letters of interest were sent to 31
firms concerning performing professional engineering services on
seven different projects. In October of 1991, a screening com-
mittee selected between 3 and 6 firms to receive Requests for
Proposals on each of the projects.
Proposals were submitted on October 31, 1991. An
evaluation committee was selected, with representatives from the
Mayor's Office, Council Office, Administrator's office and Public
Works. On November 12th and 13th, oral interviews were conducted
with each of these firms. Selection of the most qualified firm
was made for each of the projects.
The firm of BSI CONSULTANTS, INC. was selected to perform
the engineering services for the upgrade of security lights in
Perris Hill, Wildwood, Lytle Creek and Nicholson Parks. A
contract has been negotiated in accordance with the standard City
format.
The agreement provides, in general, that BSI CONSULTANTS,
INC. will prepare plans, specifications and estimates for the
project, for a fee not to exceed $20,580.00. All costs incurred
for services provided under this contract will be paid from the
approximate $200,000 allocated under Account No. 243-363-57608.
Staff recommends adoption of the resolution authorizing
execution of the agreement.
1-16-92
75.0264
22
23
24
25
26
27
28
.
.
1
RESOLUTION NO.
2 RESOLUTION OF THE CITY OF SAN BEffilARDINQ AUTHORIZING THE
EXECUTION OF AN AGREEMENT WITH BSI CONSULTANTS, INC. RELATING TO
3 THE PROVISION OF PROFESSIONAL ENGINEERING DESIGN SERVICES FOR
UPGRADE OF SECURITY LIGHTING IN PERRIS HILL, WILDWOOD, LYTLE
4 CREEK AND NICHOLSON PARKS.
5 BE IT RESOLVED BY THE MAYOR AND COMl-ION COUNCIL OF THE
CITY OF SAN BERNARDINO AS FOLLOWS:
6
7
SECTION 1. The Mayor of the City of San Bernardino is
8
hereby authorized and directed to execute, on behalf of said
9
City, an agreement with BSI Consultants, Inc. relating to the
10
provision of professional engineering design services for upgrade
11
of security lighting in Perris Hill, Wildwood, Lytle Creek, and
12
Nicholson Parks, a copy of which agreement is attached hereto,
13
marked Exhibit "A" and incorporated herein by reference as fully
14
as though set forth at length.
SECTION 2.
The agreement shall not take effect until
15
16
fully signed and executed by both parties. The City shall not be
17
obligated hereunder unless and until the agreement is fully
18
executed and no oral agreement relating thereto shall be implied
or authorized.
19
20
SECTION 3. This resolution is rescinded if the parties
21
to the agreement fail to execute it within sixty (60) days of the
passage of this resolution.
/ / / /
/ / / /
/ / / /
/ / / /
/ / / /
/ / / /
1-16-92
RESO:
AUTHOEING EXECUTION OF AGREEME~WITH BSI CONSULTANTS,
INC. TING TO PROFESSIONAL E EERING DESIGN SERVICES
FOR RADE OF SECURITY LIGHTING N PARKS.
1
2
3
4
5
6
7 REILLY
8
9
10
I HEREBY CERTIFY that the foregoing resolution was duly
adopted by
the Mayor
and
Conunon
Council of the
City of San
Bernardino
at
a
meeting thereof,
held on
the
day of
, 1992, by the following vote, to-wit:
Council Members:
AYES
NAYS
ABSTAIN
ABSENT
ESTRADA
HERNANDEZ
MAUDSLEY
MINOR
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
26
27
28
POPE-LUDLAM
MILLER
Rachel Krasney, City Clerk
The foregoing resolution is hereby approved this
day of
, 1992.
Approved as to form
and legal content:
W. R. Holcomb, Mayor
Ci ty of San Bernardino
James F. Penman
City Attorney
:J
C"/'U,
- 2 -
.
.
AGREBMENT POR PROPBSSIOHAL SBRVICBS
This AGREEMENT is made and entered into this day of
, 1992, by and between the CITY OF SAN
BERNARDINO, california, a municipal corporation, hereinafter referred
to as the "CITY" and BSI, Consultants, Inc., a California corporation,
hereinafter referred to as "ENGINEER".
WIT N E SSE T H
WHEREAS, City desires to obtain professional services to prepare
plans, specifications, estimates and construction documents for the
Security Lighting in Wildwood, perris Hill, Lytle Creek and Nicholson
Parks; and
WHEREAS, in order to develop, plans, specifications, estimates
and construction documents, it is necessary to retain the professional
services of a qualified engineering and consulting firm; and
WHEREAS, Engineer is qualified to pI:Ovide said professional
services; and
WHEREAS, San Bernardino City Council has'elected to engage the
services of Engineer upon the terms and conditions as hereinafter set
forth.
NOW, THEREFORE, it is mutually agreed, as follows:
1. SCOPE OF SERVICES
Engineer shall perform those services specified in "Scope of
services", and as contained in the proposal dated October 31, 1991, a
copy of which is attached hereto as Exhibit "1" and incorporated as
though set forth in full.
2. TERM OF AGREEMENT
The services of Engineer are to commence within thirty (30) days
after the city has authorized work to start by issuance of a Notice to
Proceed. The scheduled completion dates specifically set forth in
Exhibit "2" attached hereto and incorporated herein as though set forth
in full, will be adjusted by Engineer as the City authorizes the work.
Such adjustments shall require City approval prior to commencement of
performance of each phase. This Agreement shall expire as specified by
the Exhibit "2" schedule unless extended by written agreement of the
parties.
1
.
.
3. STANDARD OF PERFORMANCE
Engineer shall complete all work product and desig~ in confor-
mance with Standard Specifications for Public Works Construction
(Greenbook) and the city of San Bernardino's Standard Drawings.
4. CHANGES/EXTRA SERVICES
A. Performance of the work specified in the "Scope of Servic-
es", is made an obligation of Engineer under this Agreement, subject to
any changes made subsequently upon mutual agreement of the parties.
All such changes shall be incorporated by written amendments to this
Agreement and include any increase or decrease in the amount of compen-
sation due Engineer for the change in scope. Any change which has not
been so incorporated shall not be binding on either party.
B. No extra services shall be rendered by Engineer under this
Agreement unless such extra services are authorized, in writing, by
City prior to performance of such work. Authorized extra services
shall be invoiced based on Engineer's "Schedule of Hourly Rates" dated
Aoril 1. 1991 , a copy of which is attached hereto as Exhibit "4"
and incorporated herein as though set forth in full.
5. COMPENSATION
A. The City shall reimburse the Engineer for actual costs
(including labor costs, employee benefits, overhead, profit, other
direct and indirect costs) incurred by the Engineer in performance of
the work, in an amount not to exceed $20.580.00 . Actual costs shall
not exceed the estimated wage rates and other costs as set forth in
Exhibi t "3", attached hereto and incorporated herein as though set
forth in full.
B. Said compensation shall not be altered unless there is
significant alteration in the scope, complexity or character of the
work to be performed. Any such significant alteration shall be agreed
upon in writing by City and Engineer before commencement of performance
of such significant alteration by Engineer.
Any adjustment of the total cost of services will only be
permitted when the Engineer establishes and City has agreed, in
writing, that there has been, or is to be, a significant change in:
1. Scope, complexity, or character of the services to be
performed:
2. Condi tions under which the work is required to be performed:
and
3. Duration of work if the change from the time period speci-
fied in the Agreement for Completion of the work warrants
such adjustment.
2
.
.
C. The Engineer is required to comply with all Federal, state
and local laws and ordinances applicable to the work. The Engineer is
required to comply with prevailing wage rates in accordance with Calif-
ornia Labor Code section 1775.
6. PAYMENT BY CITY
A. The billings for all services rendered pursuant to this
Agreement shall be submitted monthly by Engineer to city and shall be
paid by City within twenty (20) days after receipt of same, excepting
any amounts disputed by City. Dispute over any invoiced amount shall
be noticed to the Engineer within ten (10) days of billing and a meet
and confer meeting for purposes of resolution of such dispute shall be
initiated by the city within ten (10) days of notice of such dispute.
Interest of 1-1/2 percent per month (but not exceeding the maximum rate
allowable by law) will be payable on any amounts not in dispute and not
paid within thirty (30) days of the billing date, payment thereafter to
be applied first to accrued interest and then to the principal unpaid
amount. On disputed amounts, interest shall accrue from thirty (30)
days of the invoice date if the amount in dispute is resolved in favor
of the Engineer. All tasks as specified in Exhibit "1" shall be
completed prior to final payment.
B. section 9-10 of the Cal-Trans Standard Specifications is
hereby specifically waived and not applicable to this agreement. The
parties hereto otherwise agree not to be bound by any other require-
ments for arbitration of any dispute arising hereunder. Disputes shall
be resolved by agreement of the parties, or upon the failure of such
agreement, by direct application to the Courts.
C. Should litigation be necessary to enforce any term or
provision of this Agreement, or to collect any portion of the amount
payable under this Agreement, then all litigation and collection
expenses, witness fees, and court costs, and attorney's fees shall be
paid to the prevailing party.
7. SUPERVISION AND ACCEPTANCE OF SERVICES
A. The Director of Public Works of City, or his designee, shall
have the right of general supervision over all work performed by
Engineer and shall be City's agent with respect to obtaining Engineer's
compliance hereunder. No payment for any services rendered under this
Agreement shall be made without prior approval of the Director of
Public Works or his designee.
B. The Office of the Administrator may review and inspect the
Engineer's activities during the progress of the program.
8. COMPLIANCE WITH CIVIL RIGHTS LAWS
Engineer hereby certifies that it will not discriminate against
any employee or applicant for employment because of race, color,
religion, sex, marital status or national origin. Engineer shall
promote affirmative action in its hiring practices and employee
policies for minorities and other designated classes in accordance with
3
.
.
federal, state and local laws. Such action shall include, but not be
limited to, the following: recruitment and recruitment advertising,
employment, upgrading, and promotion. In addition, Engineer shall not
exclude from participation under this Agreement any. employee or
applicant for employment on the basis of age, handicap or religion in
compliance with State and Federal laws.
9. TERMINATION OF AGREEMENT
A. This agreement may be terminated by either party upon thirty
(30) days' written notice in the event of substantial failure of the
other party to perform in accordance with the terms of this Agreement.
Each party shall have twenty (20) days following date of such notice
within which to correct the substantial failure giving rise to such
notice. In the event of termination of this Agreement, City shall
within thirty (30) days pay Engineer for all the fees, charges and
services performed to city's satisfaction by Engineer, which finding of
satisfaction shall not be unreasonably withheld. Engineer hereby
covenants and agrees that upon termination of this Agreement for any
reason, Engineer will preserve and make immediately available to City,
or its designated representatives, maps, notes, correspondence, or
records related to work paid for by the City and required for its
timely completion, and to fully cooperate with City so that the work to
be accomplished under this Agreement may continue within forty-five
(45) days of termination. Any subsequent use of such incomplete
documents shall be at the sole risk of the city and the City agrees to
hold harmless and indemnify Engineer from any claims, losses, costs,
including Attorney's fees, and liability arising out of such use.
Engineer shall be compensated for such services in accordance with
Exhibit "4".
B. This agreement may be terminated for the convenience of the
city upon thirty (30) days written notice to Engineer. Upon such
notice, Engineer shall provide work product to City and City shall
compensate Engineer in the manner set forth above.
C. Following the effective date of termination of
Agreement pursuant to this section, the Agreement shall continue
all obligations arising from such termination are satisfied.
this
until
10. CONTINGENCIES
In the event that, due to causes beyond the control of and
without the fault or negligence of Engineer, Engineer fails to meet any
of its obligations under this Agreement, and such failure shall not
constitute a default in performance, and the City may grant to Engineer
such extensions of time and make other arrangements or additions,
excepting any increase in payment, as may be reasonable under the
circumstances. Increases in payment shall be made only under the
"changes" provision of this Agreement. Engineer shall notify city
within three (3) days in writing when it becomes aware of any event or
circumstance for which it claims or may claim an extension.
4
i---U -
.
.
11. INDEPENDENT CONTRACTOR
Engineer shall act as an independent contractor in the perfor-
mance of the services provided for under this Agreement. Engineer
shall furnish such services in its own manner and in no respect shall
it be considered an agent or employee of city.
12. ASSIGNMENT OR SUBCONTRACTING
Neither this Agreement, nor any portion thereof, may be assigned
by Engineer without the written consent of city. Any attempt by
Engineer to assign or subcontract any performance of this Agreement
without the written consent of the city shall be null and void and
shall constitute a breach of this Agreement. All subcontracts
exceeding $10,000, shall contain all provisions of this contract.
13. NOTICES
All official notices
writing and addressed to the
City:
relative to this Agreement shall be in
following representatives of Engineer and
ENGINEER
CITY
BSI Consultants, Inc.
685 E. Carnegie Drive, Suite 200
San Bernardino, CA 92408
Mr. Roger Hardgrave
Director of Public Works/
City Engineer
300 North "0" Street
San Bernardino, CA 92418
14. RESPONSIBILITIES OF PARTIES
A. The Engineer may reasonably rely upon the accuracy of data
provided through the city or its agents without independent evaluation.
B. The City shall pay all costs of inspection and permit fees.
Charges not specifically covered by the terms of this Agreement shall
be paid as agreed by the parties hereto at the time such costs arise;
but in no event shall the work to be performed hereunder cease as a
consequence of any unforeseen charges unless by mutual written agree-
ment of city and Engineer.
C. All tracings, survey notes, and other original documents are
instruments of service and shall remain the property of Engineer except
where by law, precedent, or agreement these documents become public
property. All such documents or records shall be made accessible to
City. Engineer shall maintain all records for inspection by the city,
State, or their duly authorized representatives for a period of three
(3) years after final payment. Engineer shall stamp and sign all
specifications, estimates, plans and engineering data furnished, and,
where appropriate, indicate registration number.
5
.
.
15. CONSTRUCTION COST ESTIMATES
A. Any opinion of the Construction Cost prepared by Engineer
represents his judgment as a design professional and is supplied for
the general guidance of the City. Since Engineer has no control over
the cost of labor and material, or over competitive bidding or market
conditions, Engineer does not guarantee the accuracy of such opinions
as compared to contractor bids or actual cost to the City.
16. COVENANT AGAINST CONTINGENT FEE
Engineer warrants that no person or selling agency has been
employed or retained to solicit or secure this Agreement upon an
agreement or understanding for a commission, percentage, brokerage, or
contingent fee, excepting bona fide employees or bona fide established
commercial or selling agencies maintained by the Engineer for the
purpose of securing business. For breach or violation of this
warranty,' city shall have the right to terminate this Agreement in
accordance with the clause permitting termination for cause and, at its
sole discretion, to deduct from the Agreement price or consideration,
or otherwise recover, the full amount of such commission, percentage,
brokerage or contingent fee.
17. HOLD HARMLESS CAUSE
A. Engineer hereby agrees to hold City, i ts elective and
appointive boards, officers, and employees, harmless from any liability
for damage orclaims for damage for personal injury including death, as
well as from claims for property damage, which may arise from Eng-
ineer's negligent acts, errors or omissions under this Agreement.
B. Engineer shall indemnify, defend and hold free and harmless
the City, its officers and its employees from all claims, damages,
costs, expenses, and liability, including, but not limited to attor-
ney's fees imposed upon them for any alleged infringement of patent
rights or copyrights of any person or persons in consequence of the use
by City, its officers, employees, agents and other duly authorized
representatives, of programs or processes supplied to City by Engineer
under this Agreement.
18. INDEMNITY
Engineer shall indemnify, defend and hold harmless City from and
against any and all claims, demands, suits, actions, proceedings,
judgments, losses, damages, injuries, penalties, costs, expenses
(including attorney's fees) and liabilities, of, by, or with respect to
third parties, which arise solely from Engineer's negligent performance
of services under this Agreement. Engineer shall not be responsible
for, and City shall indemnify, defend and hold harmless Engineer from
and against, any and all claims, demands, suits, actions, proceedings,
judgments, losses, damages, injuries, penalties, costs, expenses
(including attorney's fees) and liabilities of, by or with respect to
third parties, which arise solely from the City's negligence. with
respect to any and all claims, demands, suits, actions, proceedings,
6
.
.
judgments, losses, damages, ~nJuries, penalties, costs, expenses
(including attorney's fees) and liabilities of, by or with respect to
third parties, which arise from the joint or concurrent negligence of
Engineer and City, each party shall assume responsibility in proportion
to the degree of its respective fault. .
19. LIABILITY/INSURANCE
A. Engineer's liability to the City for injury or damage to
persons or property arising out of work performed by the City and for
which legal liability may be found to rest upon Engineer other than for
professional errors and omissions, will be limited to $1,000,000. For
any damage on account of any error, omission or other professional
negligence Engineer's liability, will be limited to a sum not to exceed
$50,000 or Engineer's fee, whichever is greater.
B. The City will require the Engineer to provide Workers
Compensation and comprehensive general liability insurance, including
completed operations and contractual liability, with coverage suffi-
cient to insure the Engineer's indemnity, as above required; and, such
insurance will include the City, the Engineer, their consultants, and
each of their officers, agents and employees as additional insureds.
C. Engineer shall provide evidence of insurance in the form of
a policy of insurance, in which the City is named as an additional
named insured to the extent of the coverage required by this Agreement.
20. VALIDITY
Should any provision herein be found or deemed to be invalid,
this Agreement shall be construed as not containing such provision, and
all other provisions which are otherwise lawful shall remain in full
force and affect, and to this end the provisions of this Agreement are
declared to be severable.
21. ENTIRE AGREEMENT
This Agreement represents the entire and integrated agreement
between the parties hereto and supersedes all prior and contemporaneous
negotiations, representations, understandings and agreements, whether
written or oral, with respect to the subject matter thereof. This
Agreement may be amended only by written instrument signed by both
parties.
IIII
IIII
IIII
IIII
IIII
IIII
IIII
IIII
IIII
IIII
7
AG~EEMENT: PROFESS~~ ENGINEERING DESIGN SER~CES FOR SECURITY
LIGHTIN~N PERRIS HILL, WILDWOOD, ..,LE CREEK AND NICHOLSON
IN WITNESS WHEREOF, the parties hereto have caused this Agreement
to be executed on the date written above by their duly authorized
officers on their behalf.
ATTEST:
BSI CONSULTANTS, INC.
Rachel Krasney, City Clerk
By:
President
CITY OF SAN BERNARDINO,
a municipal corporation
By:
w. R. Holcomb, Mayor
Approved as to form
and legal content:
JAMES F. PENMAN
City Attorney
,~
8
.
.
EXHIBIT 1
PROJECT H - PARK LIGHTS
A. Scope of Service.
The intent of this project is to provide area security lighting which
will provide a comfort level for pedestrians~ and assist in the ability
to maintain the park facilities and reduce the potential for graffiti
and vandalism. In an initial meeting with City staff, the consultant
will define the types of lighting and the methods which might be used
to accomplish the described goals of the project.
The consultant will provide a design which meets the Illuminating
Engineers society recommended footcandle level of lighting or levels
required by City. Aesthetics and vandal resistant design criteria will
be established during meetings with appropriate staff. Following
initial design, the consultant will provide the City with recommended
standards and product information from suppliers. City staff will
assist the consultant in preparing the final design.
The consultant has conducted a site review of each of the parks and
does not anticipate any problems with the capacity of the eXisting
power systems for all four parks, assuming the appoximate number of
lights in Exhibit 3 are added. The construction drawings will be
prepared as one bid document. If necessary, the consultant can
recommend a method of bidding independent portions of each lighting
plan to allow a phasing of the construction which will keep each
project within the established budget constraints. Additional phases
could be bid and constructed at a time when additional funds are avail-
able.
Each of the individual park projects is further described below, along
with the Time Schedule and Fee/Manhour Schedule.
Specification will be per standard CDBG program requirements and the
City shall supply sample set.
DESIGN SUBMITTALS:
30% including preliminary estimate~ 75% ~ final, including a
detailed estimate.
9
.
.
EXHIBIT 2
SCHEDULE OF COMPLETION
Adivity Task Time
Notice to Proceed
I. Field Investigation and
n. L . . Selection 2 weeks
11m11121TC
m. Design Drawings
V. A. 30% Completion and Estimate 1 week
IV. City Review 1 'WllCk
m. Design Drawings
B. 75% Comp)ction 2 weeks
IV. City Review 1 week
m. Design Dmwings
C. Fma1 and Estimate 1 week
Total Design Time 6 weeks
2 weeks City Review
odmin\elec;Uic11CU""1. .Ii
~
.
.H I BIT
3
Perris HiD Park
A.4 Scope of Services
Add ten to twelve high pressure sodium Cobra Head type fixtures on twenty to thirty
foot poles - in wooded areas
Replace ten to twelve high pressure sodium fixtures - in wooded areas.
Add ten to twelve high pressure sodium fixture on thirty to forty foot poles - for
lighting of open areas.
B.4 Time Schedule
The consultant will deliver the completed project to the City within six weeks of
receiving the authorization to proceed.
C4 Schedule ManhourslFee
Activityffask Hours Rate Cost
I. Field Investigation
A. Site 12 $84 $ 1,008
B. City Mapping Files 8 $84 $ 672
II. Luminaire Selection 12 $84 $ 1,008
III. Design Drawings 24 $84 $ 2,016
IV. Review Meetings 16 $84 $ 1,344
V. Estimate (1) Final 8 $84 $ 672
Total $ 6,720
tES
.
.
Lytle Park
A.2 Scope of Services
Add four to six high pressure sodium Cobra Head type fixture mounted on thirty to
forty foot poles - for open space area.
Add four to six high pressure sodium fIXtures on twenty foot poles - to augment the
existing lighting in the wooded area.
B.2 Time Schedule
The consultant will deliver the completed project to the City within six weeks of
receiving the authorization to proceed.
C.2 Schedule ManhourslFee
Activityffask Hours Rate Cost I
I. Field Investigation
A. Site 8 $84 $ 672
B. City Mapping Files 8 $84 $ 672
II. Luminaire Selection 8 $84 $ 672
III. Design Drawings 16 $84 $ 1,344
IV. Review Meetings 16 $84 $ 1,344
V. Estimate (1) Final 6 $84 $ S04
Total $ 5,208
~
.
.
Wildwood Park
A.1 Scope of Services
Add four to six high pressure sodium Cobra Head type fixture mounted on thirty to
forty foot poles - for open space area.
Add four to six high pressure sodium fixtures on twenty foot poles - to augment the
existing lighting in the wooded area.
B.1 Time Schedule
The consultant wi!! deliver the completed project to the City within six weeks of
receiving the authorization to proceed.
C.1 Schedule ManhourslFee
Activityrrask Hours Rate Cost
I. Field Investigation
A Site 8 $84 $ 672
B. City Mapping Files 8 $84 $ 672
II. Luminaire Selection 8 $84 $ 672
III. Design Drawings 16 $84 $ 1,344
IV. Review Meetings 16 $84 $ 1,344
V. Estimate (1) Final 6 $84 $ 504
Total $ 5,208
~
.
.
Nicholson Park
A.3 Scope of Services
Add four to six high pressure sodium Cobra head type fixtures on twenty to thirty
foot poles - to provide an even distribution of light.
B.3 Time Schedule
The consultant will deliver the completed project to the City within six weeks of
receiving the authorization to proceed.
C.3 Schedule ManhourslFee
Activityffask Hours Rate Cost
I. Field Investigation
A. Site 6 $84 $ 504
B. City Mapping Files 6 $84 $ 504
II. Luminaire Selection 6 $84 $ 504
III. Design Drawings 12 $84 $ 1,008
IV. Review Meetings 8 $84 $ 672
V. Estimate (1) Final 3 $84 $ 252
Total $ 3,444
I . . .
EH:IBIT 4
BSI CONSULTANTS. INC.
SCHEDULE OF HOURLY RATES
APRIL I, 1991
HOURLY HOURLY
CLASSIFlCA nON RA1}; CLASSIFlCA nON RATE
Expert Testimony 168.00 Landscape Architect 95.00
Senior Principal Consultant 168.00 Associate Landscape Architect 89.00
Principal Consultant 142.00 Assistant Landscape Archiect 68.00
Principal Eniineer 131.00 Licensed Land Surveyor 84.00
Senior Associate 110.00 Supervisini Land Surveyor 79.00
Associate 100.00 2-Person Survey Crew 158.00
Senior Eniineer 100.00 3-Person Survey Crew 195.00
Eniineer m . 89.00 Senior Survey Analyst 79.00
Eniineer n 79.00 Survey Analyst 68.00
Eniineer I 68.00 Senior R.i&ht~f-Way Aient 89.00
Senior Specialist 100.00 R.i&ht~f.Way Aiem 68.00
Specialist m 89.00 Assistant Ri&ht~f.Way Aient 53.00
Specialist n 79.00 Senior IDspector 68.00
Specialist I 68.00 IDspector 58.00
PllIIIIer n 79.00 Senior CoDCnct .4dmini~trator 69.00
Planner I 68.00 Concnct .4dminiowvor 59.00
Senior Desiper 84.00 Nuclear Gillie Ii: Operator 47.00
Desiper 68.00 Buildini Ofticial 91.00
Senior Draftsperson 58.00 Senior ProiflllUller 74.00
Draftsperson .7.00 Proiflllllll<< 58.00
F....ineeriq Assistant 58.00 Cadd Deliper 79.00
Plan n."CUr IV 89.00 Cadd Operator D 68.00
Plan Checker m 79.00 Cadd Operator I 58.00
Plan n.",Jter D 7..00 Word Proceuor m 58.00
Plan Checker I 68.00 Word Proceuor D .7.00
Tec1mician VI 7..00 Word Proceuor I 38.00
Tec1mician V 63.00 Clerka1 32.00
Tec1mician IV 53.00 Plouer 11.00
Tec1mician m .5.00 Synerc:om Equipment 22.00
Tec1mician D 38.00
Tec1mician I 304.00
Out~f-pocket expenses (blueprintini. reproduction, and princiq) will be invoiced at cost plus 15".
A 15" fee for admini.r;ratiOD, coordination and hand1in& will be added to subconcncted services.
Mileaae will be invoiced at SO.36/mUe. 'Ibia Schedule of Hourly RateI ia effective as of April I.
1991. Rates may be adjusted after that date 10 compellSate for labor COlt iDcreasea and other
increases due 10 inflationary trends.
BSI M116 4/24/91