HomeMy WebLinkAbout1992-105
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
RESOLUTION NO. 92-105
RESOLUTION OF THE CITY OF SAN BERNARDINO AUTHORIZING THE
EXECUTION OF AN AGREEMENT WITH NBS/LOWRY ENGINEERS & PLANNERS
RELATING TO THE PROVISION OF RESIDENT ENGINEER/INSPECTION
SERVICES FOR THE SOUTH "E" STREET BRIDGE WIDENING ACROSS THE
SANTA ANA RIVER.
BE IT RESOLVED BY THE MAYOR AND COMMON COUNCIL OF THE
CITY OF SAN BERNARDINO AS FOLLOWS:
SECTION 1.
The Mavor of the City of San Bernardino is
hereby authorized and directed to execute, on behalf of said
City, an agreement with NBS/Lowry Engineers & Planners relating
to the provision of Resident Engineer/Inspection services for the
South "E" Street Bridge widening across the Santa Ana River, a
copy of which agreement is attached hereto, marked Exhibit "A"
and incorporated herein by reference as fully as though set forth
at length.
SECTION 2.
The agreement shall not take effect until
fully signed and executed by both parties. The City shall not be
obligated hereunder unless and until the agreement is fully
executed and no oral agreement relating thereto shall be implied
or authorized.
SECTION 3.
This resolution is rescinded if the parties
20
to the agreement fail to execute it within sixty (60) days of the
21
passage of this resolution.
22
23 / / / /
24 / / / /
25 / / / /
26 / / / /
27 / / / /
28 / / / /
3-03-92
RESO: AUTHORIZING EXECUTION OF AGREEMENT WITH NBS/LOWRY
ENGINEERS & PLANNERS RELATING ~Q" RESIDENT
ENGINEER/INSPECTION SERVICES FOR SOUTH "E" STREET BRIDGE.
1
I HEREBY CERTIFY that the foregoing resolution was duly
2 adopted by the Mayor and Common Council of the City of San
3 Bernardino at a regular
meeting thereof, held on the
4
l6thday of
, 1992, by the following vote, to-wit:
March
5 Council Members: AYES NAYS ABSTAIN ABSENT
6 ESTRADA X
7 REILLY x
8 HERNANDEZ x
9 MAUDSLEY X
10 MINOR x
11 POPE-LUDLAM x
12 MILLER x
13
14
15
16
17
18
19
20
21
22
23
24
25
26
27
28
~~K~a~&rk
resolution is hereby approved this i~ .tk
The foregoing
day of ~ C\}lth
/"
, 1992.
Approved as to form
and legal content:
H,lcomb, Mayor
of San Bernardino
James F. Penman
City Attorney
//,,,__ A .
.i/l../VV~
- 2 -
AGREEMENT FOR PROFESSIONAL SERVICES
This AG~EMENT is made and entered into this I~tbday of
'Y-lJ CU~ , 1991, by and between the CITY OF SAN
BERNARDINO, California, a municipal corporation, hereinafter referred
to as the "CITY" and NBS/LOWRY Engineers and Planners, a California
corporation, hereinafter referred to as "ENGINEER".
WIT N E SSE T H
WHEREAS, City desires to obtain professional services to provide
Resident Engineer and inspection services for the South "e" Street
Bridge project; and
WHEREAS, in order to provide on-site inspection, plan and shop
drawing review and administer the daily operations of the contractor as
it relates to field operations, it is necessary to retain the profes-
sional services of a qualified engineering and consulting firm; and
WHEREAS, Engineer is qualified to provide said professional
services; and
WHEREAS, San Bernardino City Council has elected to engage the
services of Engineer upon the terms and conditions as hereinafter set
forth.
NOW, THEREFORE, it is mutually agreed, as follows:
1. SCOPE OF SERVICES
Engineer shall perform those services specified in "Scope of
Services", and as contained in the proposal dated February 25, 1992,
and as modified by following phone conversations and letters covering
only Task I and Task III (per hour as directed) only, including support
staff, office and all related charges, a copy of which is attached
hereto as Exhibit "1" and incorporated as though set forth in full.
2. TERM OF AGREEMENT
The services of Engineer are to commence within thirty (30) days
after the city has authorized work to start by issuance of a Notice to
Proceed. The scheduled completion dates specifically set forth in
Exhibit "2" attached hereto and incorporated herein as though set forth
in full, will be adjusted by Engineer as the City authorizes the work.
Such adjustments shall require City approval prior to commencement of
performance of each phase. This Agreement shall expire as specified by
the Exhibit "2" schedule unless extended by written agreement of the
parties.
1
o ~
3 . STANDARD OF PERFORMANCE
Engineer shall complete all work product and design in confor-
mance with Standard Specifications for Public Works Construction
(Greenbook) and the City of San Bernardino's Standard Drawings, Project
Specifications and related Caltrans Standards referenced on the
drawings or within the specifications.
4. CHANGES/EXTRA SERVICES
A. Performance of the work specified in the "Scope of Servic-
es", is made an obligation of Engineer under this Agreement, subject to
any changes made subsequently upon mutual agreement of the parties.
All such changes shall be incorporated by written amendments to this
Agreement and include any increase or decrease in the amount of compen-
sation due Engineer for the change in scope. Any change which has not
been so incorporated shall not be binding on either party.
B. No extra services shall be rendered by Engineer under this
Agreement unless such extra services are authorized, in writing, by
City prior to performance of such work. Authorized extra services
shall be invoiced based on Engineer's "Schedule of Hourly Rates" dated
Julv 1. 1991 , a copy of which is attached hereto as Exhibit
"4" and incorporated herein as though set forth in full.
5. COMPENSATION
A. The city shall reimburse the Engineer for actual costs
(including labor costs, employee benefits, overhead, profit, other
direct and indirect costs) incurred by the Engineer in performance of
the work, in an amount not to exceed $129.170.00. Actual costs shall
not exceed the estimated wage rates and other costs as set forth in
Exhibit "3", attached hereto and incorporated herein as though set
forth in full.
B. Said compensation shall not be altered unless there is
significant alteration in the scope, complexity or character of the
work to be performed. Any such significant alteration shall be agreed
upon in writing by City and Engineer before commencement of performance
of such significant alteration by Engineer.
Any adjustment of the total cost
permitted when the Engineer establishes
writing, that there has been, or is to be,
of services will only be
and ci ty has agreed, in
a significant change in:
1. scope, complexity, or character of the services to be
performed:
2. Conditions under which the work is required to be performed:
and
3. Duration of work if the change from the time period speci-
fied in the Agreement for Completion of the work warrants
such adjustment.
2
C. The Engineer is required to comply with all Federal, state
and local laws and ordinances applicable to the work. The Engineer is
required to comply with prevailing wage rates in accordance with Calif-
ornia Labor Code section 1775.
6. PAYMENT BY CITY
A. The billings for all services rendered pursuant to this
Agreement shall be submitted monthly by Engineer to City and shall be
paid by City within twenty (20) days after receipt of same, excepting
any amounts disputed by city. Dispute over any invoiced amount shall
be noticed to the Engineer within ten (10) days of billing and a meet
and confer meeting for purposes of resolution of such dispute shall be
initiated by the city within ten (10) days of notice of such dispute.
Interest of 1-1/2 percent per month (but not exceeding the maximum rate
allowable by law) will be payable on any amounts not in dispute and not
paid within thirty (30) days of the billing date, payment thereafter to
be applied first to accrued interest and then to the principal unpaid
amount. On disputed amounts, interest shall accrue from thirty (30)
days of the invoice date if the amount in dispute is resolved in favor
of the Engineer. All tasks as specified in Exhibit "I" shall be
completed prior to final payment.
B. section 9-10 of the Cal-Trans Standard Specifications is
hereby specifically waived and not applicable to this agreement. The
parties hereto otherwise agree not to be bound by any other require-
ments for arbitration of any dispute arising hereunder. Disputes shall
be resolved by agreement of the parties, or upon the failure of such
agreement, by direct application to the Courts.
C. Should litigation be necessary to enforce any term or
provision of this Agreement, or to collect any portion of the amount
payable under this Agreement, then all litigation and collection
expenses, witness fees, and court costs, and attorney's fees shall be
paid to the prevailing party.
7. SUPERVISION AND ACCEPTANCE OF SERVICES
A. The Director of Public Works of City, or his designee, shall
have the right of general supervision over all work performed by
Engineer and shall be City's agent with respect to obtaining Engineer's
compliance hereunder. No payment for any services rendered under this
Agreement shall be made without prior approval of the Director of
Public Works or his designee.
B. The Office of the Administrator may review and inspect the
Engineer's activities during the progress of the program.
8. COMPLIANCE WITH CIVIL RIGHTS LAWS
Engineer hereby certifies that it will not discriminate against
any employee or applicant for employment because of race, color,
religion, sex, marital status or national origin. Engineer shall
promote affirmative action in its hiring practices and employee
policies for minorities and other designated classes in accordance with
3
,.
federal, state and local laws. Such action shall include, but not be
limited to, the following: recruitment and recruitment advertising,
employment, upgrading, and promotion. In addition, Engineer shall not
exclude from participation under this Agreement any employee or
applicant for employment on the basis of age, handicap or religion in
compliance with state and Federal laws.
9. TERMINATION OF AGREEMENT
A. This agreement may be terminated by either party upon thirty
(30) days' written notice in the event of substantial failure of the
other party to perform in accordance with the terms of this Agreement.
Each party shall have twenty (20) days following date of such notice
within which to correct the substantial failure giving rise to such
notice. In the event of termination of this Agreement, City shall
within thirty (30) days pay Engineer for all the fees, charges and
services performed to City's satisfaction by Engineer, which finding of
satisfaction shall not be unreasonably withheld. Engineer hereby
covenants and agrees that upon termination of this Agreement for any
reason, Engineer will preserve and make immediately available to city,
or its designated representatives, maps, notes, correspondence, or
records related to work paid for by the city and required for its
timely completion, and to fully cooperate with city so that the work to
be accomplished under this Agreement may continue within forty-five
(45) days of termination. Any subsequent use of such incomplete
documents shall be at the sole risk of the city and the city agrees to
hold harmless and indemnify Engineer from any claims, losses, costs,
including Attorney's fees, and liability arising out of such use.
Engineer shall be compensated for such services in accordance with
Exhibit "4".
B. This agreement may be terminated for the convenience of the
ci ty upon thirty (30) days written notice to Engineer. Upon such
notice, Engineer shall provide work product to City and City shall
compensate Engineer in the manner set forth above.
C. Following the effective date of termination of
Agreement pursuant to this section, the Agreement shall continue
all obligations arising from such termination are satisfied.
this
until
10. CONTINGENCIES
In the event that, due to causes beyond the control of and
without the fault or negligence of Engineer, Engineer fails to meet any
of its obligations under this Agreement, and such failure shall not
constitute a default in performance, and the City may grant to Engineer
such extensions of time and make other arrangements or additions,
excepting any increase in payment, as may be reasonable under the
circumstances. Increases in payment shall be made only under the
"changes" provision of this Agreement. Engineer shall notify city
within three (3) days in writing when it becomes aware of any event or
circumstance for which it claims or may claim an extension.
4
'.1
11. INDEPENDENT CONTRACTOR
Engineer shall act as an independent contractor in the perfor-
mance of the services provided for under this Agreement. Engineer
shall furnish such services in its own manner and in no respect shall
it be considered an agent or employee of city.
12. ASSIGNMENT OR SUBCONTRACTING
Neither this Agreement, nor any portion thereof, may be assigned
by Engineer without the written consent of City. Any attempt by
Engineer to assign or subcontract any performance of this Agreement
without the written consent of the City shall be null and void and
shall constitute a breach of this Agreement. All subcontracts
exceeding $10,000, shall contain all provisions of this contract.
13. NOTICES
All official notices relative to this Agreement shall be in
writing and addressed to the following representatives of Engineer and
city:
ENGINEER
CITY
NBS/LOWRY Engineers and Planners
17748 Skypark Circle
Irvine, CA 92714-6468
Mr. Roger Hardgrave
Director of Public Works/
City Engineer
300 North "D" Street
San Bernardino, CA 92418
14. RESPONSIBILITIES OF PARTIES
A. The Engineer may reasonably rely upon the accuracy of data
provided through the City or its agents without independent evaluation.
B. The City shall pay all costs of inspection and permit fees.
charges not specifically covered by the terms of this Agreement shall
be paid as agreed by the parties hereto at the time such costs arise;
but in no event shall the work to be performed hereunder cease as a
consequence of any unforeseen charges unless by mutual written agree-
ment of city and Engineer.
c. All tracings, survey notes, and other original documents are
instruments of service and shall remain the property of Engineer except
where by law, precedent, or agreement these documents become public
property. All such documents or records shall be made accessible to
city. Engineer shall maintain all records for inspection by the City,
state, or their duly authorized representatives for a period of three
(3) years after final payment. Engineer shall stamp and sign all
specifications, estimates, plans and engineering data furnished, and,
where appropriate, indicate registration number.
5
15. CONSTRUCTION COST ESTIMATES
A. Any opinion of the Construction Cost prepared by Engineer
represents his judgment as a design professional and is supplied for
the general guidance of the City. Since Engineer has no control over
the cost of labor and material, or over competitive bidding or market
conditions, Engineer does not guarantee the accuracy of such opinions
as compared to contractor bids or actual cost to the City.
16. COVENANT AGAINST CONTINGENT FEE
Engineer warrants that no person or selling agency has been
employed or retained to solicit or secure this Agreement upon an
agreement or understanding for a commission, percentage, brokerage, or
contingent fee, excepting bona fide employees or bona fide established
commercial or selling agencies maintained by the Engineer for the
purpose of securing business. For breach or violation of this
warranty, City shall have the right to terminate this Agreement in
accordance with the clause permitting termination for cause and, at its
sole discretion, to deduct from the Agreement price or consideration,
or otherwise recover, the full amount of such commission, percentage,
brokerage or contingent fee.
17. HOLD HARMLESS CAUSE
A. Engineer hereby agrees to hold City, its elective and
appointive boards, officers, and employees, harmless from any liability
for damage orclaims for damage for personal injury including death, as
well as from claims for property damage, which may arise from Eng-
ineer's negligent acts, errors or omissions under this Agreement.
B. Engineer shall indemnify, defend and hold free and harmless
the city, its officers and its employees from all claims, damages,
costs, expenses, and liability, including, but not limited to attor-
ney's fees imposed upon them for any alleged infringement of patent
rights or copyrights of any person or persons in consequence of the use
by city, its officers, employees, agents and other duly authorized
representatives, of programs or processes supplied to City by Engineer
under this Agreement.
18. INDEMNITY
Engineer shall indemnify, defend and hold harmless city from and
against any and all claims, demands, suits, actions, proceedings,
judgments, losses, damages, injuries, penalties, costs, expenses
(including attorney's fees) and liabilities, of, by, or with respect to
third parties, which arise solely from Engineer'S negligent performance
of services under this Agreement. Engineer shall not be responsible
for, and City shall indemnify, defend and hold harmless Engineer from
and against, any and all claims, demands, suits, actions, proceedings,
judgments, losses, damages, injuries, penalties, costs, expenses
(including attorney's fees) and liabilities of, by or with respect to
third parties, which arise solely from the City's negligence. with
respect to any and all claims, demands, suits, actions, proceedings,
6
judgments, losses, damages, injuries, penalties, costs, expenses
(including attorney's fees) and liabilities of, by or with respect to
third parties, which arise from the joint or concurrent negligence of
Engineer and City, each party shall assume responsibility in proportion
to the degree of its respective fault.
19. LIABILITY/INSURANCE
A. Engineer's liability to the City for injury or damage to
persons or property arising out of work performed by the City and for
which legal liability may be found to rest upon Engineer other than for
professional errors and omissions, will be limited to $1,000,000. For
any damage on account of any error, omission or other professional
negligence Engineer's liability, will be limited to a sum not to exceed
$50,000 or Engineer's fee, whichever is greater.
B. The city will require the Engineer to provide Workers
compensation and comprehensive general liability insurance, including
completed operations and contractual liability, with coverage suffi-
cient to insure the Engineer's indemnity, as above required; and, such
insurance will include the city, the Engineer, their consultants, and
each of their officers, agents and employees as additional insureds.
C. Engineer shall provide evidence of insurance in the form of
a policy of insurance, in which the City is named as an additional
named insured to the extent of the coverage required by this Agreement.
20. VALIDITY
Should any provision herein be found or deemed to be invalid,
this Agreement shall be construed as not containing such provision, and
all other provisions which are otherwise lawful shall remain in full
force and affect, and to this end the provisions of this Agreement are
declared to be severable.
21. ENTIRE AGREEMENT
This Agreement represents the entire and integrated agreement
between the parties hereto and supersedes all prior and contemporaneous
negotiations, representations, understandings and agreements, whether
written or oral, with respect to the subject matter thereof. This
Agreement may be amended only by written instrument signed by both
parties.
fill
fill
fill
fill
fill
fill
fill
fill
fill
fill
fill
fill
7
,.., )
AGREEMENT RESIDENT ENGINEER/INSPECTION SERVICES FOR SOUTH
"E" STREET BRIDGE WIDENING
IN WITNESS WHEREOF, the
to be executed on the date
officers on their behalf.
ATTEST:
RA~~~
Approved as to form
and legal content:
JAMES F. PENMAN
City Attorney
r
By: iht i7>4 I
(;
f
f .(l-'~>v__
parties hereto have caused this Agreement
written above by their duly authorized
NBS/LOWRY ENGINEERS & PLANNERS
&;,~ft
/' -e ,/1"5/ t7 n
CITY OF SAN BERNARDINO,
a municipal corporation
8
SENT BY:NBS/LOWRY
3- 9-92 2:55PM
IRVINE~ENGINEERING
;# 3
IlDIBI'1' "1"
"SCOPI! OJ/' SBRVICIlS"
CITY OJ/' SAN BERNARDINO
BOUTH "B" STREET BRIDIIB
NilS/Lowry SQOp. of service. for the City of San Bernardino,
South "E" Street Bridge Widenin", projeot i. a. follow.:
TASK I - CONSTRUCTION PHAlI
NBS/Lowry will furnish the services of a full time
Resident Engineer for a period of one hundred ninety
(190) construction (working) days (8 hours/day) for the
South "E" Street Bridge Wideninq projeot.
The city of San Bernardino will furnish the full time
inspection stat! required tor the proper inspection
durin", the Construction Phase.
'1'ASlt II - PROJ!OT OLOS! OUT PHASE
NBS/Lowry services for TASK II (Project Close out Phase)
are not included in this Scope of Services.
TASK III - SHOP DRaWING RBVIEW
NBS/Lowry will furnish the services of office personnel
for the review of Shop Drawings submitted by the
Contractor. This service is estimated at one hundred
(100) hours of review time.
Task III services will be performed only when authorized
in writing by the City.
The agreed to NBS/Lowry hourly rates set forth in Exhibit "3"
for TASK I and TASK III services are inclusive of NBS/Lowry
support staff, vehicle costs, clerical costs etc.
-# / j;:;
;:''/'.- :l". '''I=~, _...Il''''i'
, ". ~;. "
--- . - - ~
. " . '- -,.... ','-- '.. '..
BXHIBIT "2"
SCHBDULED COHP~ITIOH DATil
CUy OF SAN BlJUfARDIHO
80UTH "B" STUJlT BllIDGIl PROJBCT
The antioipated Construction Schedule for this Project .i8 as
follows:
April 1, 1992 - Begin Construction
Oecember 31, 1992 - End Construction
Ths Scheduled Completion Date for this Project i. Deoember
31, 1992.
The SCheduled Completion Date includes one hundred ninety
(190) construction days and seven (7) holidays. Saturdays,
sundays and HOlidays are not included as construction
(working) days.
(,
\
'. 5~NT. BY: NB5/.CWfiY
... 8-~2 ,::S;ly1
:~J:~~-:~G:~::~:\~
EDISIT "3"
SCHEDULED 0' WAGI RATI'
CITY OJ' SAN B!JUJAJU):nl'O
SOUTH "." STUBT BRIDGB PROJBCT
The waqe rates to be invoiced by NBS/Lowry tor the services
pertormed on this project are as follows:
TASK I
The services of the NBS/Lowry Resident En~ineer will be
invoiced on an hourly basis at $79.36/hour. This rate
include. the normal service. of the NBS/Lowry support
staff, vehicle costs, clerical staft, etc.
This hourly rate does not include overtime services
(over 8 hours/day, 40 hours/week, work on weekendS,
and/or holidays) for the Resident Engineer or other
support staff.
TASK II
NBS/Lowry services for shop drawinq review will b.
invoiced on an hourly basis at $85.42/hour for each hour
worked by the engineer/technician performing the review.
This rate includes the normal services of the NBS/Lowry
support staft, vehicle costs, clerical service., etc.
;; :
~) - \ ,) )
'.
SENT BY:NBS/LOWRY
3- 8-82
2:55PM;
:~vINE-ENGINEERING
;; c
EXIIIBIT "4"
I
NBSt'\
\.1 tOWRY
IHllHiS I 'lAiNEI!
SCHEDULE OF HOURlY BILLING RATES
Eff.ctive July 1.1991
OFFICE
En,lnl.,ln,1 P1annln,
Senior Principal
Principal
Principal Envineer/Plonner
Stniar Engineer/PIanner
Envin,"/P1ann"
A$Jilfant Envineer/Plonner
1135.00
115.00
95.00
85.00
70,00
55.00
Dul,n and Draftln,
Senior Ollivner
Oui;ner
S.niar Orofter
Droher
Envinllrin; Technician
170.00
65.00
55.00
45.00
40.00
fiELD
(an.lnletlon Mlnl'lmlnl
Principal Envineer/Construction MVr
S.nior Enginllr/Conllruclion Mgr
Rtlid.nt Envineer/Co"'truc~on EnV
AII~tont Conltruction Engineer
In'peclor
2.1x Direct Salary
2.h Direct Salary
2.8. Direct Salary
2.1x Direct Salary
2.8. Direct Salary
Sur"yl.,
Principal Survtyor
S.nior Surv.yor
Suptrvilin; Surv.yor
Surve, Technician
Surn, Crew 13 p.rtonl
Survty Crew (2 Penonl
1 ravel Time
MillOge ISurvey lruck)
195.00
85.00
10.00
45.00
115.00
140.00
SO" x Crew Rot.
.lO/MiI,
SERVICES AND lXPENHS
Syll.ml Analyst/Sr Financial Anoly.'
Programmer/Financial Anal,.t
S.nior l.chnician
1 echnician
hituli.. Stcntory/Admin Alliston!
Secretory
Word Preceller/CI.rk/Omce Aid.
S85.00
65.00
55.00
45.00
45.00
40.00
35.00
Computtn:
Moinfromt Conntel Timt
PC Conn.ct Time
Oilk Sloreg.IPer Mbl
Report" 1525.00 Minimuml
lin.. Printtd
CPU lim.
Photocopill
Mileog.
Sub.lIl.nc.
Other E.penlll
IJo.oO/Hour
10.001Hour
m.JO/Monlh
.02/lin'
.sO/S,cend
.lO/Copy
.321MiI.
AI Cod
COlt + 15"
Silling rotll include overhead and ore lubj.ctlo increOlel each ytOr due 10 union borgoininv ogr..",enll and
Call of IivinV increasel.
A lot, payment FINANCE CHARGE will b. appli.d 10 any unpaid bolonc., commencing thirly (JO) days aher the dot. of th. original
invoice. at th. maximum inlertlt rot, ollow.d by law.
6/91
Coverage Part No.: Policy Number: QB849539000
Commercial General Liability
THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY.
ADDITIONAL INSURED-OWNERS. LESSEES OR CONTRACTORS (FORM Bl
This endorsement modifies insurance provided under the following:
COMMERCIAL GENERAL LIABILITY COVERAGE PART
WHO IS AN INSURED (Section II) is amended to include as an insured the
person or organization shown in the Schedule, but only with respect to
liability arising out of "your work" for that insured by or for you.
SCHEDULE
Name of person or oraanization:
City of San Bernardino, Its Officers,
Agents, and Employees
300 North "0" Street
San Bernardino, CA. 92418
CG2010 (ED. 11-85)
,. ..~
....A.~.tltlt. ::IIIIIIIIIII~llillllllll.
::\i::::W::::::t~:t:{i::::~:I::::t!:::::1:::::::t::[::::::::i::::t::(m~J'~:;g~f~}U'U}gg~
PRODUCER
HEMET INSURANCE
P . 0 . BOX 119 7
Hemet, CA 92546
SERVICE, INC.
.."".""""","', 0 3 0 3 9 2
THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND
CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE
DOES NOT AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE
POLICIES BELOW.
COMPANIES AFFORDING COVERAGE
t~~~~NY A Reliance Insurance Company
INSURED
NBS/Lowry, Incorporated
Att: Mr. William Amadon
P.O. Box 28100
San Diego, CA 92128
f~f'f~~NY B
f~T"i~~NY C
f~f'f~iNY D
f~r"i~~NY E
THIS IS TO CERTlFY THAT THE POLICIES OF INSURANCE L1STlED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD
INDICATED, NOTWITHSTANDING ANY REQUIREMENT, TlERM OR CONDmON OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS
CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS.
EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS.
CO TYPE OF INSURANCE POLICY NUMBER POLICY EFFECTIVE lICY EXPIRATION LIMITS
lTR DATE(MM/DDfYY) DATE(MM/DD/YY)
A C3ENERAlllABllITY QB849539000 GENERAL AGGREGATE , 2 000 00
OMMERCIAl GENERAL L1ABILI PRODUCTS-COMP/OP AGG. , 2 000 00
LA1MSMADE mOCCUR. PERSONAL &ADY.INJURY , 1 000 00
WNER'S & CONTRACTOR'S PROTo EACH OCCURRENCE , 1 000 00
FIRE DAMAGE (Anyone fire) $ 50 00
MED.EXPENSE (Anyone person) $ 5 00
A AUTOMOBilE LIABILITY QB849539000 COMBINED SINGLE , 1,000,00
X ANY AUTO LIMIT
ALL OWNED AUTOS BODilY INJURY ,
SCHEDULED AUTOS (Per person)
X HIRED AUTOS BODILY INJURY $
X NON-OWNED AUTOS (Per accident)
GARAGE LIABILITY
PROPERTY DAMAGE ,
A EXCE99 LIABILITY QU849523901
X UMBAELLAFORM
OTHER THAN UMBRELLA FORM
A WORKER'S COMPENSATION QR02988800
AND
EMPLOYERS' LIABILITY DISEASE-POLICY LIMIT
DISEASE-EACH EMPLOYEE
OTH ER
DESCRIPTION OF OPERATIONS/LOCATlONS/VEHIClES/SPECIAL ITEMS
RE: Construction Engineering Services - South "E" Street Bridge
The Certificate Holder is named as Additional Insured per attached
form CG2010.
City of San Bernardino
ATT: Gene R Klatt, Ast. City Engr.
300 North "D" Street
San Bernardino, CA 92418
SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE
EXPIRATION DATE THEREOF, THE ISSUING COMPANY WlLL elJ8~eA T8
MAIL ~ DAYS WRITTEN NOTlCE TO THE CERTlFICATlE HOLDER NAMED TO THE
LEFT. Bl:fT F. JIORIii T~ ..." ~"g~1 "............r- ~U611 IlADr\~e tiS e8~8A1iI8U eA
~A':',,,,,,, u, ...,J, Ill/IS MfSIJ." Ie:: 3ol,lf:~U\, Pt'5 ):,6e,J,.... un nl;;;,'........I;;;."...i"r:E:Br
'ifil'N.. ...A. ..... ~AC6iiij...
. -- .
92
THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS
NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AMEND,
EXTEND OR AlTEA THE COVERAGE AFFORDED BYTHE POLICIES BElOW
PRODUCER
ROBSON, CAVIGNAC & ASSOC
P. O. BOX 80187
SAN DIEGO CA 92138
COMPANIES AFFORDING COVERAGE
INSURED
NBS/LOWRY, INCORPORATED
P.O. BOX 28100
SAN DIEGO, CA 92198
COMPANY A
LETTER
COMPANY
B
LETTER
COMPANY C
LETTER
COMPANY
D
lETTER
COMPANY
E
LETTER
LEXINGTON
THIS IS TO CERTIFY THAT THE POLICIes OF INSURANce LISTED BelOW HAVE BEEN ISSUED lOTHE INSURED NAMED ABOVE FOR THE POLICY PERIOD
INDICATED, NOTWITHSTANDING ANYREaUIREMENT, TEAM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECTIO WHICH THIS
CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BYTHE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS,
EXCLUSIONS AND CONDITIONS OF SUCH POLlCIES. LIMITS SHOWN MAY HAVE BEEN REDUCED BYPAID CLAIMS.
co
TYPE OF INSURANCE POLICY NUMBER All LIMITS IN THOUSANDS
TA DATE (MM/CD
GENERAL lIABILITY GENERAL AGGREGATE I
COMMERCIAL GENERAL LlABILI PRODUCTS-COMP/OPS AGGR I
CLAIMS MAODOCCUA. PERSONAL & ADVERTISING INJUR I
OWNER'S &CONTRACTOR'S PROT EACH OCCURR ENCE .
FIRE DAMAGE(Anyone fire) I
MEDICAL EXPENSE (Anyone per.on
AUTOMOBilE llABILlTY COMBINED
SINGLE I
ANY AUTO LIMIT
All OWNED AUTOS BODilY
INJURY I
SCH EDUlED AUTOS (Per person)
HIRED AUTOS BODILY
INJURY I
NON-OWNED AUTOS (Per ace)
GARAGE LIABILITY PROPERTY
DAMAGE I
EXCESS lIABILITY EACH
OCCUR.
I I
OTHER THAN UMBRELLA FORM
WORKER'S COMPENSATION
I (EACH ACCIDENT)
ANa
I (DISEASE-POlleY LIMIT)
EMPLOYERS' LIABILITY
I (DISEASE-EACH EMPLOYEE
OTH. PROFESSIONAL PC5630731 02/03/92 02/03/93 2,000,000EA CLM
LIABILITY PC5630731 02/03/92 02/03/93 2,000,000ANN AG
DESCRIPTION OF OPERA T10NS/LOCATIONSjVEHIClES/SPECIAL ITEMS
RE: .CONSTRUCTION ENGINEERING SERVICES - SOUTH "E" STREET BRIDGE.
CITY OF SAN BERNARDINO
300 NORTH "n" STREET
SAN BERNARDINO, CA 92418
SHOULD ANYOFTHE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE
EXPIRATION DATE THEREOF. THE ISSUING COMPANY WILL ENDEAVOR TO
MAlllD- DAYS WRITIEN NOTICE TOTHE CERTIFICATE HOLDER NAMED lOTHE
LEFT. BUT FAILURE TO MAil SUCH NOTice SHALL IMPOSE NO OBLIGATION OR
lIABILITY OF ANY KIND UPON THE COMPANY. ITS AGENTS OR REPRESENTATIVES.
AUTHORIZED REPRESENTATIVE