Loading...
HomeMy WebLinkAbout1992-054 ," ., 1 RESOLUTION NO. 92-54 2 RESOLUTION OF THE CITY OF SAN BERNARDINO AUTHORIZING THE EXECUTION OF AN AGREEMENT WITH P & D TECHNOLOGIES RELATING TO THE 3 PROVISION OF PROFESSIONAL ENGINEERING DESIGN SERVICES FOR REHABILITATION OF SOUTH "E" STREET, FROM ORANGE SHOW ROAD TO MILL 4 STREET. 5 BE IT RESOLVED BY THE MAYOR AND COMMON COUNCIL OF THE CITY OF SAN BERNARDINO AS FOLLOWS: 6 7 8 9 10 11 12 13 14 15 16 17 18 19 20 21 22 23 24 SECTION 1. The Mayor of the City of San Bernardino is hereby authorized and directed to execute, on behalf of said City, an agreement with P & D Technologies relating to the provision of professional engineering design services for the rehabilitation of South "E" Street, from Orange Show Road to Mill Street, a copy of which agreement is attached hereto, marked Exhibit "A" and incorporated herein by reference as fully as though set forth at length. SECTION 2. The agreement shall not take effect until fully signed and executed by both parties. The City shall not be obligated hereunder unless and until the agreement is fully executed and no oral agreement relating thereto shall be implied or authorized. SECTION 3. This resolution is rescinded if the parties to the agreement fail to execute it within sixty (60) days of the passage of this resolution. / / / / / / / / / / / / / / / / / / / / / / / / 25 26 27 28 1-23-92 RESO: AUTHORIZING EXECUTION OF AGREEMENT WITH P & D TECHNOLOGIES RE~ATIN~ TO PROFESSIONAL ENGINEERING DESIGN SEEVICES FOR REHABILITATION OF SOUTH "E" STREET. 92-54 1 I HEREBY CERTIFY that the foregoing resolution was duly 2 adopted by the Mayor and Cormnon Council of the City of San 3 Bernardino at a regular meeting thereof, held on the 4 17th day of February , 1992, by the following vote, to-wit: 5 Council Members: 6 ESTRADA 7 REILLY 8 HERNANDEZ 9 MAUDSLEY 10 MINOR 11 POPE-LUDLAM AYES NAYS ABSTAIN ABSENT x x x x x x 12 MILLER 13 14 15 16 day of 17 18 x (g~s~ The foregoing resolution is hereby approved this ;I~~ 19 7 ..<? / ~/' />;' "W.(R. H lcomb, Mayor City of 'San Bernardino February , 1992. Approved as to form 20 and legal content: 21 James F. Penman City Attorney 22 23 24 J (;..~--- 25 26 27 28 - 2 - 1- .~ Exhibit A AGREEMENT FOR PROFESSIONAL SERVICES 4~L.. Th~s AGREEMENT is made and entered into this day of 1I11J1U.J..... , 1992, by and between the CITY OF SAN BERNARDINO, California, a municipal corporation, hereinafter referred to as the "CITY" and P & D Technologies, a California corporation, hereinafter referred to as "ENGINEER". WIT N E SSE T H WHEREAS, city desires to obtain professional services to prepare plans, specifications, estimates and construction documents for the Rehabilitation of South "E" Street from Orange Show road to Mill Street; and WHEREAS, in order to develop, plans, specifications, estimates and construction documents, it is necessary to retain the professional services of a qualified engineering and consulting firm; and WHEREAS, Engineer is qualified to provide said professional services; and WHEREAS, San Bernardino City Council has elected to engage the services of Engineer upon the terms and conditions as hereinafter set forth. NOW, THEREFORE, it is mutually agreed, as follows: 1. SCOPE OF SERVICES Engineer shall perform those services specified in "Scope of Services", and as contained in the proposal dated October 31, 1991, a copy of which is attached hereto as Exhibit "1" and incorporated as though set forth in full. 2. TERM OF AGREEMENT The services of Engineer are to commence within thirty (30) days after the City has authorized work to start by issuance of a Notice to Proceed. The scheduled completion dates specifically set forth in Exhibit "2" attached hereto and incorporated herein as though set forth in full, will be adjusted by Engineer as the City authorizes the work. Such adjustments shall require City approval prior to commencement of performance of each phase. This Agreement shall expire as specified by the Exhibit "2" schedule unless extended by written agreement of the parties. .1:3,;j(:. 1 3. STANDARD OF PERFORMANCE Engineer shall complete all work product and design in confor- mance with Standard Specifications for Public Works Construction (Greenbook) and the City of San Bernardino's Standard Drawings. 4. CHANGES/EXTRA SERVICES A. Performance of the work specified in the "Scope of Servic- es", is made an obligation of Engineer under this Agreement, subject to any changes made subsequently upon mutual agreement of the parties. All such changes shall be incorporated by written amendments to this Agreement and include any increase or decrease in the amount of compen- sation due Engineer for the change in scope. Any change which has not been so incorporated shall not be binding on either party. B. No extra services shall be rendered by Engineer under this Agreement unless such extra services are authorized, in writing, by city prior to performance of such work. Authorized extra services shall be invoiced based on Engineer's "Schedule of Hourly Rates" dated December 30. 1991 ,a copy of which is attached hereto as Exhibit "4" and incorporated herein as though set forth in full. 5. COMPENSATION A. The city shall reimburse the Engineer for actual costs (including labor costs, employee benefits, overhead, profit, other direct and indirect costs) incurred by the Engineer in performance of the work, in an amount not to exceed $42.598.00 Actual costs shall not exceed the estimated wage rates and other costs as set forth in Exhibit "3", attached hereto and incorporated herein as though set forth in full. B. Said compensation shall not be altered unless there is significant alteration in the scope, complexity or character of the work to be performed. Any such significant alteration shall be agreed upon in writing by city and Engineer before commencement of performance of such significant alteration by Engineer. Any adjustment of the permitted when the Engineer writing, that there has been, total cost establishes or is to be, of services will only be and City has agreed, in a significant change in: 1. Scope, complexity, or character of the services to be performed; 2. conditions under which the work is required to be performed; and 3. Duration of work if the change from the time period speci- fied in the Agreement for Completion of the work warrants such adjustment. 2 C. The Engineer is required to comply with all Federal, state and local laws and ordinances applicable to the work. The Engineer is required to comply with prevailing wage rates in accordance with Calif- ornia Labor Code section 1775. 6. PAYMENT BY CITY A. The billings for all services rendered pursuant to this Agreement shall be submitted monthly by Engineer to City and shall be paid by City within twenty (20) days after receipt of same, excepting any amounts disputed by city. Dispute over any invoiced amount shall be noticed to the Engineer within ten (10) days of billing and a meet and confer meeting for purposes of resolution of such dispute shall be initiated by the City within ten (10) days of notice of such dispute. Interest of 1-1/2 percent per month (but not exceeding the maximum rate allowable by law) will be payable on any amounts not in dispute and not paid within thirty (30) days of the billing date, payment thereafter to be applied first to accrued interest and then to the principal unpaid amount. On disputed amounts, interest shall accrue from thirty (30) days of the invoice date if the amount in dispute is resolved in favor of the Engineer. All tasks as specified in Exhibit "1" shall be completed prior to final payment. B. Section 9-10 of the Cal-Trans Standard Specifications is hereby specifically waived and not applicable to this agreement. The parties hereto otherwise agree not to be bound by any other require- ments for arbitration of any dispute arising hereunder. Disputes shall be resolved by agreement of the parties, or upon the failure of such agreement, by direct application to the Courts. C. Should litigation be necessary to enforce any term or provision of this Agreement, or to collect any portion of the amount payable under this Agreement, then all litigation and collection expenses, witness fees, and court costs, and attorney's fees shall be paid to the prevailing party. 7. SUPERVISION AND ACCEPTANCE OF SERVICES A. The Director of Public Works of city, or his designee, shall have the right of general supervision over all work performed by Engineer and shall be City's agent with respect to obtaining Engineer's compliance hereunder. No payment for any services rendered under this Agreement shall be made without prior approval of the Director of Public Works or his designee. B. The Office of the Administrator may review and inspect the Engineer's activities during the progress of the program. 8. COMPLIANCE WITH CIVIL RIGHTS LAWS Engineer hereby certifies that it will not discriminate against any employee or appl icant for employment because of race, color, religion, sex, marital status or national origin. Engineer shall promote affirmative action in its hiring practices and employee pOlicies for minorities and other designated classes in accordance with 3 federal, state and local laws. Such action shall include, but not be limited to, the following: recruitment and recruitment advertising, employment, upgrading, and promotion. In addition, Engineer shall not exclude from participation under this Agreement any employee or applicant for employment on the basis of age, handicap or religion in compliance with State and Federal laws. 9. TERMINATION OF AGREEMENT A. This agreement may be terminated by either party upon thirty (30) days' written notice in the event of substantial failure of the other party to perform in accordance with the terms of this Agreement. Each party shall have twenty (20) days following date of such notice within which to correct the substantial failure giving rise to such notice. In the event of termination of this Agreement, City shall within thirty (30) days pay Engineer for all the fees, charges and services performed to City's satisfaction by Engineer, which finding of satisfaction shall not be unreasonably withheld. Engineer hereby covenants and agrees that upon termination of this Agreement for any reason, Engineer will preserve and make immediately available to City, or its designated representatives, maps, notes, correspondence, or records related to work paid for by the City and required for its timely completion, and to fully cooperate with city so that the work to be accomplished under this Agreement may continue within forty-five (45) days of termination. Any subsequent use of such incomplete documents shall be at the sole risk of the City and the City agrees to hold harmless and indemnify Engineer from any claims, losses, costs, including Attorney's fees, and liability arising out of such use. Engineer shall be compensated for such services in accordance with Exhibit "4". B. This agreement may be terminated for the convenience of the city upon thirty (30) days written notice to Engineer. Upon such notice, Engineer shall provide work product to city and City shall compensate Engineer in the manner set forth above. C. Following the effective date of termination of Agreement pursuant to this section, the Agreement shall continue all obligations arising from such termination are satisfied. this until 10. CONTINGENCIES In the event that, due to causes beyond the control of and without the fault or negligence of Engineer, Engineer fails to meet any of its obligations under this Agreement, and such failure shall not constitute a default in performance, and the City may grant to Engineer such extensions of time and make other arrangements or additions, excepting any increase in payment, as may be reasonable under the circumstances. Increases in payment shall be made only under the "changes" provision of this Agreement. Engineer shall notify City within three (3) days in writing when it becomes aware of any event or circumstance for which it claims or may claim an extension. 4 11. INDEPENDENT CONTRACTOR Engineer shall act as an independent contractor in the perfor- mance of the services provided for under this Agreement. Engineer shall furnish such services in its own manner and in no respect shall it be considered an agent or employee of city. 12. ASSIGNMENT OR SUBCONTRACTING Neither this Agreement, nor any portion thereof, may be assigned by Engineer without the written consent of city. Any attempt by Engineer to assign or subcontract any performance of this Agreement without the written consent of the City shall be null and void and shall constitute a breach of this Agreement. All subcontracts exceeding $10,000, shall contain all provisions of this contract. 13 . NOTICES All official notices relative to this Agreement shall be in writing and addressed to the following representatives of Engineer and City: ENGINEER CITY P & D Technologies 650 East Hospitality Lane suite 350 San Bernardino, CA 92408 Mr. Roger Hardgrave Director of Public Works/ City Engineer 300 North "D" Street San Bernardino, CA 92418 14. RESPONSIBILITIES OF PARTIES A. The Engineer may reasonably rely upon the accuracy of data provided through the city or its agents without independent evaluation. B. The City shall pay all costs of inspection and permit fees. Charges not specifically covered by the terms of this Agreement shall be paid as agreed by the parties hereto at the time such costs arise; but in no event shall the work to be performed hereunder cease as a consequence of any unforeseen charges unless by mutual written agree- ment of city and Engineer. C. All tracings, survey notes, and other original documents are instruments of service and shall remain the property of Engineer except where by law, precedent, or agreement these documents become public property. All such documents or records shall be made accessible to City. Engineer shall maintain all records for inspection by the city, State, or their duly authorized representatives for a period of three (3) years after final payment. Engineer shall stamp and sign all specifications, estimates, plans and engineering data furnished, and, where appropriate, indicate registration number. 5 15. CONSTRUCTION COST ESTIMATES A. Any opinion of the Construction Cost prepared by Engineer represents his judgment as a design professional and is supplied for the general guidance of the City. Since Engineer has no control over the cost of labor and material, or over competitive bidding or market conditions, Engineer does not guarantee the accuracy of such opinions as compared to contractor bids or actual cost to the city. 16. COVENANT AGAINST CONTINGENT FEE Engineer warrants that no person or selling agency has been employed or retained to solicit or secure this Agreement upon an agreement or understanding for a commission, percentage, brokerage, or contingent fee, excepting bona fide employees or bona fide established commercial or selling agencies maintained by the Engineer for the purpose of securing business. For breach or violation of this warranty, City shall have the right to terminate this Agreement in accordance with the clause permitting termination for cause and, at its sole discretion, to deduct from the Agreement price or consideration, or otherwise recover, the full amount of such commission, percentage, brokerage or contingent fee. 17. HOLD HARMLESS CAUSE A. Engineer hereby agrees to hold City, its elective and appointive boards, officers, and employees, harmless from any liability for damage orclaims for damage for personal injury including death, as well as from claims for property damage, which may arise from Eng- ineer's negligent acts, errors or omissions under this Agreement. B. Engineer shall indemnify, defend and hold free and harmless the City, its officers and its employees from all claims, damages, costs, expenses, and liability, including, but not limited to attor- ney's fees imposed upon them for any alleged infringement of patent rights or copyrights of any person or persons in consequence of the use by city, its officers, employees, agents and other duly authorized representatives, of programs or processes supplied to City by Engineer under this Agreement. 18. INDEMNITY Engineer shall indemnify, defend and hold harmless City from and against any and all claims, demands, suits, actions, proceedings, judgments, losses, damages, injuries, penalties, costs, expenses (including attorney's fees) and liabilities, of, by, or with respect to third parties, which arise solely from Engineer'S negligent performance of services under this Agreement. Engineer shall not be responsible for, and city shall indemnify, defend and hold harmless Engineer from and against, any and all claims, demands, suits, actions, proceedings, judgments, losses, damages, injuries, penalties, costs, expenses (including attorney's fees) and liabilities of, by or with respect to third parties, which arise solely from the City's negligence. with respect to any and all claims, demands, suits, actions, proceedings, 6 1- judgments, losses, damages, injuries, penalties, costs, expenses (including attorney's fees) and liabilities of, by or with respect to third parties, which arise from the joint or concurrent negligence of Engineer and City, each party shall assume responsibility in proportion to the degree of its respective fault. 19. LIABILITY/INSURANCE A. Engineer's liability to the city for injury or damage to persons or property arising out of work performed by the City and for which legal liability may be found to rest upon Engineer other than for professional errors and omissions, will be limited to $1,000,000. For any damage on account of any error, omission or other professional negligence Engineer's liability, will be limited to a sum not to exceed $50,000 or Engineer's fee, whichever is greater. B. The city will require the Engineer to provide Workers Compensation and comprehensive general liability insurance, including completed operations and contractual liability, with coverage suffi- cient to insure the Engineer's indemnity, as above required; and, such insurance will include the city, the Engineer, their consultants, and each of their officers, agents and employees as additional insureds. C. Engineer shall provide evidence of insurance in the form of a policy of insurance, in which the city is named as an additional named insured to the extent of the coverage required by this Agreement. 20. VALIDITY Should any provision herein be found or deemed to be invalid, this Agreement shall be construed as not containing such provision, and all other provisions which are otherwise lawful shall remain in full force and affect, and to this end the provisions of this Agreement are declared to be severable. 21. ENTIRE AGREEMENT This Agreement represents the entire and integrated agreement between the parties hereto and supersedes all prior and contemporaneous negotiations, representations, understandings and agreements, whether written or oral, with respect to the subject matter thereof. This Agreement may be amended only by written instrument signed by both parties. IIII IIII IIII IIII IIII IIII IIII IIII IIII IIII 7 AGREEMENT: DESIGN SERVICES FOR REHABILITATION OF SOUTH "E" STREET ORANGE SHOW ROAD TO MILL STREET IN WITNESS WHEREOF, the parties hereto have caused this Agreement to be executed on the date written above by their duly authorized officers on their behalf. RA~NE~rk ATTEST: CITY OF SAN BERNARDINO, a municipal cor\~ation B0~d ) " Valerie Pope-Ludlam, Mayor Pro Tem Approved as to form and legal content: JAMES F. PENMAN city Attorney 7- ~ 8 I , EXHIBIT 1 SCOPE OF WORK Task 1. PRE-DESIGN MEETINGS P&D Technologies will meet with the City of San Bernardino to refine the specific project scope and client desires. The meeting will result in identification of key contacts, unresolved issues, design constraints, a schedule and preferably a job walk with representatives from the City's Engineering and Maintenance team. Task 2. RESEARCH/FIELD REVIEW A thorough search of available records will be conducted to acquire relevant data to assist in the design of the project. The information accumulated will include as-built drawings, utility information, right-of-way descriptions, and horizontal and vertical control data. Task3. SURVEY The P&D Project Team will provide the necessary existing survey information required to design the project including topographical features and cross section data. As discussed with the City, -- P&D will survey from north of the Orange Show Road intersection to south of the Mill Street intersection, but will not survey the two major intersections. Cross sections will be taken at 50 foot intervals for the length of the project from curb to curb only. The only survey information collected in the parkway area will be the horizontal location of the driveways and the existing street signs. Cross section and topo data on the intersecting streets will only extend to the curb returns. Construction surveying and resetting of monuments after construction are not included in our scope of services. Task 4. UTILITY COORDINATION The utility companies will be notified of the proposed project and the location of facilities within the project limits will be requested. Coordination with the utilities will continue throughout the design of the project. A copy of the utility file will be provided to the City. Task S. PAVEMENT EVALUATION The P&D Project Team will take four core samples to a maximum depth of four feet. One sample will be taken in each travel lane. Laboratory testing will be performed to determine the R- Value of the samples. Using the core data and subgrade soil conditions, a component analysis will be made to determine if the current structural section meets the design criteria. Recommendations will be based on general field observations and the "average" conditions or "worse case" conditions encountered, which could result in conservative recommendations. No pavement deflection testing will be performed. Task 6. STREET IMPROVEMENTS Forty-scale plan and profile street improvement plans will be prepared for South "E" Street from Orange Show Road to Mill Street. Based on our discussions with the City, we have assumed that all existing curb and gutter is in good condition and will not be reconstructed. However, 1 short reaches of obvious drainage problems will be addressed and corrected on the plans. Plotted cross sections will be prepared to ensure adequate cross-fall and joins. Cross sections will not be prepared in a format appropriate for inclusion in the plan set. We are anticipating a title/detail sheet, and five plan sheets. The various construction techniques that will be utilize don thejob (cold plane, overlay, reconstruct) will be delineated by various types of shading and through the use of a legend. Task 7. STRIPING PLANS Forty-scale double plan format signing and striping plans will be prepared for the length of the project. The plans will reflect existing striping and signing without any revisions. Striping plans shall show sidewalk, driveway approaches, median islands and all other existing improvements that affect turning movements. Separate traffic control/detour plans are not included in our scope of services. However, traffic control during construction will be adequately addressed in the specifications. Task 8. COST ESTIMATES Preliminary cost estimates will be prepared for the proposed improvements and included with the first plan check submittal. Final construction cost estimates will be prepared based on the final improvement plans. Prepared forms with quantities will also be part of the specification h preparation. As a part of this effort, P&D will do an analysis of the reconstruction methods identified in the materials report to determine the relative costs of the procedures as well as other advantages and disadvantages of each method. Task 9. SPECIFICATIONS Standard specifications will be prepared for the project based on the standard Specifications for public Works Construction for roadway construction and based on Caltrans specifications for traffic issues. City will provide sample format of specification to be used as a guide. Task 10. MEETINGS Progress prints will be delivered to the City at each status meeting to allow the City to review the progress made during the preceding period. P&D will attend the following meetings with the City: · Pre-design meeting · Two (2) status meetings . Final submittal meeting . Such other working meetings deemed necessary to complete the work and as requested by P&D P&D will provide three sets of plans and specifications for each City Review. 2 SERVICES SlJPPJ.Tli'.D BY CITY The City of San Bernardino will be responsible for assisting the Engineer in obtaining the following: 1. All available existing data, information, reports and maps available in City files for existing improvements and information on City-owned utilities. 2. All required copies of plans and specifications for the project bid documents. 3. All necessary environmental documentation for the project. 4. Sample specifications for similar projects including City boilerplate. 5. Blank mylar with City title block. 6. Standard City title sheet. 7. Pothole information, if needed and not provided by utility owners. 8. Pavement coring data and deflection testing. EXCLUSIONS Specifically excluded from the services to be performed under the provisions of this proposal are the following: 1. Any services related to right-of-way acquisition. 2. Modifications to the existing traffic signals (except preservation or replacement of damaged traffic loop detectors). 3. Landscape and irrigation plans. 4. Construction administration. 3 EXHIBIT 2 .-. - - - - - - - - - - - - - " ~ ... .. n ~ ~ .. .. ;! ... ,i " II " I! " II j1 ,~ " - - - - - - - !I Jf "" ~ ... :i " II '! !i li " J: il n " 1 n u I :! '! j, z 1\ : " II ~ I 11 !i 'I ii "- 'I ii '" ~ I I, .., \, , , !, " % '" , , J~ jl d .... i '" ~ ,~ ..Ii.. f ir .,.,. i~ ~ ~ ,~ ... ! ii !I ii !' - .... II " ! ~ i, il u ..i II Ii ;: :!: ;i '" " ii u - :1 '" ~ d !! I , ,,n "- :1 J Ii , q !i , , 'I " " , , , J I , :i !! , , , , ,~. , ..... _l - - - - - - - ., , " "" ... I i ,I , , 'i iI , i! J , , , , , I , , , , ! , , " I J Ii , ,; ! , , , ,I , :; , .J. , ," ~ - - - - - - - - - ...;. , ..... " ... , , ~ , '" ; , ~ ,,, , , , , , , , , '" " , ,." , .... ~ ... , Z ,~ ... , .., ... , , ~ , .., 4 , - u T , '" , .... ,." , .... ~ ~ , ~ .... .. , '" '" - * , '" ~ '" * , .... '" "- '" , % Z '" .. -0 .. , .... % 3! z ~ .... z: , '" .... '" :: .z ,~ , ~ .... ~ '" :: - , ::; .... '" ", .... - Z , '" .., - .... ~ , .... '" <> Z 4 z: '" Z' ,n , ~ ~ ~ .. '" '" .... ,,n ,n z , ,,, "- 4 '" ~ '" ~ '" "- .... z '" , '" ~ '" 4: '" - :: .. , '. '" "" '" := "" .... '" , ~ '" .... ~ ~ - .. .. , % .... '" .. .... .... '" "" , ill - Z ~ - ::: .... .... ,,n , .... '" "" '" '" '" '" , '" ,:;; - .... - .. .... ~ .... .... :!! , .., ~ .... '" '" ~ ~ , .... 0> ~ .... .... z - U 4: .., - , = '" '" "" := '" '" .... N N Z :!! .... , ~ .... '" ;; 4: '" "- => "" II! , ~ '" '" "- '" '" u '" ..., ~ ~ ~ , '" "" :c ... '" Uol.:!.... u :::c .~ !!. :='I ::. I:) Q ~ ~ 'A,:po ... '" .=> ... - ::z ........ 4: ~ ~ ~ - ... '" Q ~ ... .~ ~~i ~ Q i~~ :c '" z .... '" '" ... ... ... '" n => ~ ~ ~ Z ~.,., "" .:......0 <oft n .. z ... "- ... ~ '" ~ a '" << .... .. a ~ ... ..n '" "" ~ ~ Q "'~ =~~ ~ '" '" Z Q '" '" .... ~ '" ~~ ~!i! ~ '" '" '" 7'.... ~ ... ~ '" '" ~ '" ... "- '" '" Z ... ~ .. '" '" "" 'n .~ ~ ~ .~ :; - . 0- - => ,'- ~ ., .. . = ~ '" a! ~ Q ~ ci ~ ~ g s: 2 g g e eo .::> ~ g ~~O"~;;~~~ - Q> .;) .0 .QoO':l>OO'~<:I=OO o ~ ..., - ..., '" '" '" .. ~ Co CD <:::) ,=> '" _0 ..Q""'", - .... ;~;ggOQ'=-~:i ,_,.., N...a N ,.... C"'ol",,,,,, _ ~~__g~~~O'::'Qo.:t~ '" '" 0'''''''00 oc,;::" OOQ 0.,:,0 0 N CD OCDQoO.:>QOOQOQoOO' - ~ oO,:.......,OO.::loO_OO.o.=>_ '" ... OOOo.o....o_OQOO'::>.o r-"" <""'" '" 0.0000...0_00000.::>.:::;.0.0 0- ~ ~.::lo~O:i:O~'=O'=O:loQo aJ'::lo_OS:~ ..a.oooQo:>..o '" .. OC:OO_O:::-_l%lO'::>O.:lo..o ,~ .-... C"'ol N N <""... N N ,...... N ....... N ("'''' <""'" o--O"'o-o-o-\:I"'cr-o-~o-a-o-o-- .0 ;;: .;; 0- 0; ~ .-::; 0 ...., ....... CD ...., ..., N.=>C"""NNI~'" .::>:.....('".1 "------. -.---. C'",,,,,,,~""____"""_II':I,,'lI") OOOOQO.::>O.=-'~oo.::> 1.-'" N N ,'-.1 N ....... l..... ,-.... N .....1 C'.... ("'oj ,...... O-CI'" 0"'0'-0-0-0" Cl'-O"'O'-O"'cr-o- ...., ,..... ...... ...:0 '-"'1 ,.., 0- .-;; .0 - ....., ~=--e ....... NC"'ol.::>_C"....::> ~ .~ ~ ~~ '~ ~ ..~ ~ ..;: ....... ~ .g '~ s ... ~ .. Z '" Z '" '" ~ Z :i:;:~?i '" ... IC:I -J ~ ... "'." '" ~ g~:f~ :r: w ~~ w _z >.D ~ _""-I :z: -<.:I: l.U :c......, .....>....JuJ.....:z <..oJ ~'5=;z:=(.CI~~ .:z:; (,1'1 _ ... U1 V'I ....) IJ1 > > ... ... .:J:o%~a _;:; ~ :z: :z ~ ...,.-. u.,..... 11: ,.. ... '" ~ Z => s "'::l '" ... ~ '" CD Z => ~ ... '" ~ ... Z ..:2 "':;;: ",::! ...~ ss ...... > ~ '" ~ '" ~ ." '" 0- .,., '" - o o ~. ..., <SO ... '" '" ..., - .., .., '" - <> ~ '" - <> c. '" ,~ <SO .~ => .., . . . . ~ ~ ." ~ Q . . . . EXHIBIT 3 ~ ~ ~ ~ c ~ ~ ~ ~ 5 :5 ~ '5 .5a;~~ --:,:. ..:;. ~ 0, _-=>.-::> =,.,::> 1.1' - ~ ..., ~ ... " u .. u ~ " " ~ .. '" ,. '" ... ~.....~ .;.ex uJ..... u..l W W ~ ::z uJ .:z::. 4: z =-c: Z.;.D uJ ..... <l:Zo;.o :z: >tn .c.....z::z~ .:a:uJ 1.10I<1: ....l=.:a: _ 1I:.;..J cI: en (..J W :z:: en t...J __ ::;~"='I..o.~=~~ QC_"'IC:Wu"I::I:" .z:.:z:I"UCl:uJ.....ll:::! ... .::I c::I (..J.........I') " " ..z:.::ouaa.....u.,<:.=.:z: P & D TECHNOLOGIES SCHEDULE OF FEES 3O-Dec-91 I PRINCIPALS : I PRINCIPAL-iN-CHARGE $ / HOUR $150 LABOR CHARGE RATES IENVlRONMENTAL; I PROJECT ENVIR. ANALYST SR. ENVIR. ANALYST/SPECIAUST ENVIR. ANAL YST/SPECIAUST SR. RESEARCHER RESEARCHER $120 $/HOUR $100 $85 $75 $65 $55 I PROJ. MANAGERS; I SR PROJECT MANAGER I ENGINEERS; PROJECT ENGINEER SR. ENGINEER ENGINEER DESIGN ENGINEER SR. DESIGNER DESIGNER SR. DRAFTER/CADD OPER. DRAFTERlCADD OPER. ENGINEERING TECHNICIAN $100 $90 $80 $65 $80 $65 $65 $50 $40 ITRANSP. PLANNERS; I PROJECT TRANSP. PLANNER SR. TRANSP. PLANNER TRANSP. PLANNER TRANSP. SYSTEM ANALYST TRANSP. TECHNICIAN $100 $90 $70 $60 $40 I PLANNERS; PROJECT PLANNER SR. PLANNER PLANNER SR. PLANNING TECHNICIAN PLANNING TECHNICIAN IECONOMISTS : SR. ECONOMIST ECONOMIST ECONOMIC ANALYST $120 $95 $65 $100 $90 $80 $70 $45 I LANDSCAPE ARCHITECTS; PROJECT LAND. ARCHITECT SR. LAND. ARCHITECT LAND. ARCHITECT STAFF LAND. ARCHITECT $100 $90 $75 $60 I OTHER STAFF: WORDPROCESSING REPORT PREP./EDITING PROJECT CONTROL $55 $50 $55 I GRAPHICS: SR. GRAPHICS GRAPHICS $65 $50 REIMBURSABLE EXPENSES I HANDUNG FEE . MILEAGE REPRODUCTION SINGLE SIDED REPRODUCTION TWO SIDED 15.00% $0.25/MILE $0.05/COPY $0.07/COPY VISUAL SIMULATION /HOUR CADD/COMPUTER TIME /HOUR DEUVERIES /HOUR REPRODUCTION 11 X 17 /COPY $25 $25 $30 $0.20 'INCLUDES REPOFfT PRINTlNGlREPRODUCnON. GRAPHIC AIDS. TRAVEL(AIRFARE.MEALS.ErC.). FEES BY GOVERNING BODIES. COMPUTER SERVICES. PHOTOGRAPHY. SUBCONTRACT SERVICES. POSTAGE. TELEPHONE;FAX AND DEUVERY. ACCOUNTS ARE DUE AND PAYABLE WITHIN 30 DAYS OF THE DATE OF THE INVOICE. PAST DUE ACCOUNTS WILL HAVE A FINANCE CHARGE OF I.~ PER MONTH COMPOUNDED. ALL RATES MAYBE SUBJECT 10 CHANGE AT SUCH nME AS ADJUSTMENTS ARE MADE AS A RESULTOF AGREEMENTS. SALARY AD.AJSTMENTS AND INCREASED BUSINESS EXPENSES. I RATES EFFECTIVE THRU: IZISIM AGREEMENT FOR PROFESSIONAL SERVICES This AGREEMENT is made and entered into this day of , 1992, by and between the CITY OF SAN BERNARDINO, California, a municipal corporation, hereinafter referred to as the "CITY" a.nd P & D Technologies, a California corporation, hereinaft.er referred to as "ENGINEER". WIT N E SSE T H WHEREAS, City desires to obtain professional services to prepare plans, specifications, estimates and construction documents for the Rebabilitation of South "E" Street from Orange Show road to Mill st.reet; and WHEREAS, in order to develop, plans, specifications, estimates and construction documents, it is necessary to retain the professional services of a qualified engineering and consulting firm; and WHEREAS, Engineer is qualified to provide said professional services; and WHEREAS, San Bernardino City Council has elected to engage the services of Engineer upon the terms and conditions as hereinafter set forth. NOW, THEREFORE, it is mutually agreed, as follows: 1. SCOPE OF SERVICES Engineer shall perform those services specified in "Scope of Services", and as contained in the proposal dated October 31, 1991, a copy of which is attached hereto as Exhibit "1" and incorporated as though set forth in full. 2. TERM OF AGREEMENT The services of Engineer are to commence within thirty (30) days after the City has authorized work to start by issuance of a Notice to Proceed. The scheduled completion dates specifically set forth in Exhibit "2" attached hereto and incorporated herein as though set forth in full, will be adjusted by Engineer as the City authorizes the work. Such adjustments shall require City approval prior to commencement of perfOTl1Hl.l1C", of each phase. This AgreelGont. shall expire as specified by the Exhibit "?" schedule unless exttHl<:kd by written agreement of the parties. 1 3. STANDARD OF PERFORMANCE Engineer shall complete all work product and design in confor- mance with Standard specifications for Public Works Construction (Greenbook) and the City of San Bernardino's Standard Drawings. 4. CHANGES/EXTRA SERVICES A. Performance of the work specified in the "Scope of Servic- es", is made an obligation of Engineer under this Agreement, subject to any changes made subsequently upon mutual agreement of the parties. All such changes shall be incorporated by written amendments to this Agreement and include any increase or decrease in the amount of compen- sation due Engineer for the change in scope. Any change which has not been so incorporated shall not be binding on either party. B. No extra services shall be rendered by Engineer under this Agreement unless such extra services are authorized, in writing, by City prior to performance of such work. Authorized extra services shall be invoiced based on Engineer's "Schedule of Hourly Rates" dated December 30. 1991 , a copy of which is attached hereto as Exhibit "4" and incorporated herein as though set forth in full. 5. COMPENSATION A. The City shall reimburse the Engineer for actual costs (including labor costs, employee benefits, overhead, profit, other direct and indirect costs) incurred by the Engineer in performance of the work, in an amount not to exceed $42.598.00 Actual costs shall not exceed the estimated wage rates and other costs as set forth in Exhibit "3", attached hereto and incorporated herein as though set forth in full. B. Said compensation shall not be altered unless there is significant alteration in the scope, complexity or character of the work to be performed. Any such significant alteration shall be agreed upon in writing by City and Engineer before commencement of performance of such significant alteration by Engineer. Any adjustment of the permitted when the Engineer writing, that there has been, total cost establishes or is to be, of services will only be and city has agreed, in a significant change in: 1. Scope , complexity, or character of the services to be performed; 2. Condi tions under which the work is required to be performed; and 3. Duration of work if the change from the time period speci- fied in the Agreement for Completion of the work warrants such adjustment. 2 , . C. The Engineer is required to comply with all Federal, state and local laws and ordinances applicable to the work. The Engineer is required to comply with prevailing wage rates in accordance with Calif- ornia Labor Code Section 1775. 6. PAYMENT BY CITY A. The billings for all services rendered pursuant to this Agreement shall be submitted monthly by Engineer to City and shall be paid by city within twenty (20) days after receipt of same, excepting any amounts disputed by city. Dispute over any invoiced amount shall be noticed to the Engineer within ten (10) days of billing and a meet and confer meeting for purposes of resolution of such dispute shall be initiated by the City within ten (10) days of notice of such dispute. Interest of 1-1/2 percent per month (but not exceeding the maximum rate allowable by law) will be payable on any amounts not in dispute and not paid within thirty (30) days of the billing date, payment thereafter to be applied first to accrued interest and then to the principal unpaid amount. On disputed amounts, interest shall accrue from thirty (30) days of the invoice date if the amount in dispute is resolved in favor of the Engineer. All tasks as specified in Exhibit "1" shall be completed prior to final payment. B. section 9-10 of the Cal-Trans Standard Specifications is hereby specifically waived and not applicable to this agreement. The parties hereto otherwise agree not to be bound by any other require- ments for arbitration of any dispute arising hereunder. Disputes shall be resolved by agreement of the parties, or upon the failure of such agreement, by direct application to the Courts. C. Should litigation be necessary to enforce any term or provision of this Agreement, or to collect any portion of the amount payable under this Agreement, then all litigation and collection expenses, witness fees, and court costs, and attorney's fees shall be paid to the prevailing party. 7. SUPERVISION AND ACCEPTANCE OF SERVICES A. The Director of Public Works of city, or his designee, shall have the right of general supervision over all work performed by Engineer and shall be City's agent with respect to obtaining Engineer's compliance hereunder. No payment for any services rendered under this Agreement shall be made without prior approval of the Director of Public Works or his designee. B. The Office of the Administrator may review and inspect the Engineer's activities during the progress of the program. 8. COMPLIANCE WITH CIVIL RIGHTS LAWS Engineer hereby certifies that it will not discriminate against any employee or applicant for employment because of race, color, religion, sex, marital status or national origin. Engineer shall promote affirmative action in its hiring practices and employee policies for minorities and other designated classes in accordance with 3 , ' federal, state and local laws. Such action shall include, but not be limited to, the following: recruitment and recruitment advertising, employment, upgrading, and promotion. In addition, Engineer shall not exclude from participation under this Agreement any employee or applicant for employment on the basis of age, handicap or religion in compliance with State and Federal laws. 9. TERMINATION OF AGREEMENT A. This agreement may be terminated by either party upon thirty (30) days' written notice in the event of substantial failure of the other party to perform in accordance with the terms of this Agreement. Each party shall have twenty (20) days following date of such notice within which to correct the substantial failure giving rise to such notice. In the event of termination of this Agreement, city shall within thirty (30) days pay Engineer for all the fees, charges and services performed to City's satisfaction by Engineer, which finding of satisfaction shall not be unreasonably withheld. Engineer hereby covenants and agrees that upon termination of this Agreement for any reason, Engineer will preserve and make immediately available to City, or its designated representatives, maps, notes, correspondence, or records related to work paid for by the City and required for its timely completion, and to fully cooperate with City so that the work to be accomplished under this Agreement may continue within forty-five (45) days of termination. Any subsequent use of such incomplete documents shall be at the sole risk of the City and the City agrees to hold harmless and indemnify Engineer from any claims, losses, costs, including Attorney's fees, and liability arising out of such use. Engineer shall be compensated for such services in accordance with Exhibit "4". B. This agreement may be terminated for the convenience of the City upon thirty (30) days written notice to Engineer. Upon such notice, Engineer shall provide work product to city and City shall compensate Engineer in the manner set forth above. C. Following the effective date of termination of Agreement pursuant to this section, the Agreement shall continue all obligations arising from such termination are satisfied. this until 10. CONTINGENCIES In the event that, due to causes beyond the control of and without the fault or negligence of Engineer, Engineer fails to meet any of its obligations under this Agreement, and such failure shall not constitute a default in performance, and the City may grant to Engineer such extensions of time and make other arrangements or additions, excepting any increase in payment, as may be reasonable under the circumstances. Increases in payment shall be made only under the "changes" provision of this Agreement. Engineer shall notify city within three (3) days in writing when it becomes aware of any event or circumstance for which it claims or may claim an extension. 4 11. INDEPENDENT CONTRACTOR Engineer shall act as an independent contractor in the perfor- mance of the services provided for under this Agreement. Engineer shall furnish such services in its own manner and in no respect shall it be considered an agent or employee of City. 12. ASSIGNMENT OR SUBCONTRACTING Neither this Agreement, nor any portion thereof, may be assigned by Engineer without the written consent of City. Any attempt by Engineer to assign or subcontract any performance of this Agreement without the written consent of the City shall be null and void and shall constitute a breach of this Agreement. All subcontracts exceeding $10,000, shall contain all provisions of this contract. 13. NOTICES All official notices relative to this Agreement shall be in writing and addressed to the following representatives of Engineer and City: ENGINEER CITY P & 0 Technologies 650 East Hospitality Lane suite 350 San Bernardino, CA 92408 Mr. Roger Hardgrave Director of Public Works/ City Engineer 300 North "0" Street San Bernardino, CA 92418 14. RESPONSIBILITIES OF PARTIES A. The Engineer may reasonably rely upon the accuracy of data provided through the City or its agents without independent evaluation. B. The City shall pay all costs of inspection and permit fees. Charges not specifically covered by the terms of this Agreement shall be paid as agreed by the parties hereto at the time such costs arise; but in no event shall the work to be performed hereunder cease as a consequence of any unforeseen charges unless by mutual written agree- ment of City and Engineer. C. All tracings, survey notes, and other original documents are instruments of service and shall remain the property of Engineer except where by law, precedent, or agreement these documents become public property. All such documents or records shall be made accessible to City. Engineer shall maintain all records for inspection by the City, State, or their duly authorized representatives for a period of three (3) years after final payment. Engineer shall stamp and sign all specifications, estimates, plans and engineering data furnished, and, where appropriate, indicate registration number. 5 15. CONSTRUCTION COST ESTIMATES A. Any opinion of the Construction Cost prepared by Engineer represents his judgment as a design professional and is supplied for the general guidance of the City. Since Engineer has no control over the cost of labor and material, or over competitive bidding or market conditions, Engineer does not guarantee the accuracy of such opinions as compared to contractor bids or actual cost to the City. 16. COVENANT AGAINST CONTINGENT FEE Engineer warrants that no person or selling agency has been employed or retained to solicit or secure this Agreement upon an agreement or understanding for a commission, percentage, brokerage, or contingent fee, excepting bona fide employees or bona fide established commercial or selling agencies maintained by the Engineer for the purpose of securing business. For breach or violation of this warranty, City shall have the right to terminate this Agreement in accordance with the clause permitting termination for cause and, at its sole discretion, to deduct from the Agreement price or consideration, or otherwise recover, the full amount of such commission, percentage, brokerage or contingent fee. 17. HOLD HARMLESS CAUSE A. Engineer hereby agrees to hold city, its elective and appointive boards, officers, and employees, harmless from any liability for damage orclaims for damage for personal injury including death, as well as from claims for property damage, which may arise from Eng- ineer's negligent acts, errors or omissions under this Agreement. B. Engineer shall indemnify, defend and hold free and harmless the City, its officers and its employees from all claims, damages, costs, expenses, and liability, including, but not limited to attor- ney's fees imposed upon them for any alleged infringement of patent rights or copyrights of any person or persons in consequence of the use by City, its officers, employees, agents and other duly authorized representatives, of programs or processes supplied to City by Engineer under this Agreement. 18. INDEMNITY Engineer shall indemnify, defend and hold harmless City from and against any and all claims, demands, suits, actions, proceedings, judgments, losses, damages, injuries, penalties, costs, expenses (including attorney's fees) and liabilities, of, by, or with respect to third parties, which arise solely from Engineer's negligent performance of services under this Agreement. Engineer shall not be responsible for, and City shall indemnify, defend and hold harmless Engineer from and against, any and all claims, demands, suits, actions, proceedings, judgments, losses, damages, injuries, penalties, costs, expenses (including attorney's fees) and liabilities of, by or with respect to third parties, which arise solely from the City's negligence. With respect to any and all claims, demands, suits, actions, proceedings, 6 judgments, losses, damages, injuries, penalties, costs, expenses (including attorney's fees) and liabilities of, by or with respect to third parties, which arise from the joint or concurrent negligence of Engineer and City, each party shall assume responsibility in proportion to the degree of its respective fault. 19. LIABILITY/INSURANCE A. Engineer's liability to the City for injury or damage to persons or property arising out of work performed by the City and for which legal liability may be found to rest upon Engineer other than for professional errors and omissions, will be limited to $1,000,000. For any damage on account of any error, omission or other professional negligence Engineer's liability, will be limited to a sum not to exceed $50,000 or Engineer's fee, whichever is greater. B. The City will require the Engineer to provide Workers Compensation and comprehensive general liability insurance, including completed operations and contractual liability, with coverage suffi- cient to insure the Engineer's indemnity, as above required: and, such insurance will include the City, the Engineer, their consultants, and each of their officers, agents and employees as additional insureds. C. Engineer shall provide evidence of insurance in the form of a policy of insurance, in which the City is named as an additional named insured to the extent of the coverage required by this Agreement. 20. VALIDITY Should any provision herein be found or deemed to be invalid, this Agreement shall be construed as not containing such provision, and all other provisions which are otherwise lawful shall remain in full force and affect, and to this end the provisions of this Agreement are declared to be severable. 21. ENTIRE AGREEMENT This Agreement represents the entire and integrated agreement between the parties hereto and supersedes all prior and contemporaneous negotiations, representations, understandings and agreements, whether written or oral, with respect to the subject matter thereof. This Agreement may be amended only by written instrument signed by both parties. IIII IIII IIII IIII IIII IIII IIII IIII IIII IIII 7 AGREEMENT: PROFESSIONAL ENGINEERING DESIGN SERVICES ; IN WITNESS WHEREOF, the parties hereto have caused this Agreement to be executed on the date written above by their duly authorized officers on their behalf. l. . (/- ~{vt~L/ !r//t'C/~ j ATTEST: By: / L P & D TECHNOLOGIES (EN~INE~R) ~~[::_( /i;", pr~ident ATTEST: CITY OF SAN BERNARDINO, a municipal corporation Rachel Krasney, City Clerk By: W. R. Holcomb, Mayor Approved as to form and legal content: JAMES F. PENMAN City Attorney By: 8 EXHmIT 1 SCOPE OF WORK Task 1. PRE-DESIGN MEETINGS P&D Technologies will meet with the City of San Bernardino to refine the specific project scope and client desires. The meeting will result in identification of key contacts, unresolved issues, design constraints, a schedule and preferably a job walk with representatives from the City's Engineering and Maintenance team. Task 2. RESEARCH/FIELD REVIEW A thorough search of available records will be conducted to acquire relevant data to assist in the design of the project. The information accumulated will include as-built drawings, utility information, right-of-way descriptions, and horizontal and vertical control data. Task 3. SURVEY The P&D Project Team will provide the necessary existing survey information required to design the project including topographical features and cross section data. As discussed with the City, P&D will survey from north of the Orange Show Road intersection to south of the Mill Street intersection, but will not survey the two major intersections. Cross sections will be taken at 50 foot intervals for the length of the project from curb to curb only. The only survey information collected in the parkway area will be the horizontal location of the driveways and the existing street signs. Cross section and topo data on the intersecting streets will only extend to the curb returns. Construction surveying and resetting of monuments after construction are not included in our scope of services. Task 4. UTILITY COORDINATION The utility companies will be notified of the proposed project and the location of facilities within the project limits will be requested. Coordination with the utilities will continue throughout the design of the project. A copy of the utility file will be provided to the City. Task 5. PAVEMENT EVALUATION The P&D Project Team will take four core samples to a maximum depth of four feet. One sample will be taken in each travel lane. Laboratory testing will be performed to determine the R- Value of the samples. Using the core data and subgrade soil conditions, a component analysis will be made to determine if the current structural section meets the design criteria. Recommendations will be based on general field observations and the "average" conditions or "worse case" conditions encountered, which could result in conservative recommendations. No pavement deflection testing will be performed. Task 6. STREET IMPROVEMENTS Forty-scale plan and profile street improvement plans will be prepared for South "E" Street from Orange Show Road to Mill Street. Based on our discussions with the City, we have assumed that all existing curb and gutter is in good condition and will not be reconstructed. However, I short reaches of obvious drainage problems will be addressed and corrected on the plans. Plotted cross sections will be prepared to ensure adequate cross-fall and joins. Cross sections will not be prepared in a format appropriate for inclusion in the plan set. We are anticipating a title/detail sheet, and five plan sheets. The various construction techniques that will be utilize don the job (cold plane, overlay, reconstruct) will be delineated by various types of shading and through the use of a legend. Task 7. STRIPING PLANS Forty-scale double plan format signing and striping plans will be prepared for the length of the project. The plans will reflect existing striping and signing without any revisions. Striping plans shall show sidewalk, driveway approaches, median islands and all other existing improvements that affect turning movements. Separate traffic control/detour plans are not included in our scope of services. However, traffic control during construction will be adequately addressed in the specifications. Task 8. COST ESTIMATES Preliminary cost estimates will be prepared for the proposed improvements and included with the first plan check submittal. Final construction cost estimates will be prepared based on the final improvement plans. Prepared forms with quantities will also be part of the specification preparation. As a part of this effort, P&D will do an analysis of the reconstruction methods identified in the materials report to determine the relative costs of the procedures as well as other advantages and disadvantages of each method. Task9. SPEC~CATIONS Standard specifications will be prepared for the project based on the standard Specifications for public Works Construction for roadway construction and based on Caltrans specifications for traffic issues. City will provide sample format of specification to be used as a guide. Task 10. MEETINGS Progress prints will be delivered to the City at each status meeting to allow the City to review the progress made during the preceding period. P&D will attend the following meetings with the City: · Pre-design meeting · Two (2) status meetings · Final submittal meeting . Such other working meetings deemed necessary to complete the work and as requested by P&D P&D will provide three sets of plans and specifications for each City Review. 2 SERVICES SUPPLIED BY CITY The City of San Bernardino will be responsible for assisting the Engineer in obtaining the following: 1. All available existing data, information, reports and maps available in City files for existing improvements and information on City-owned utilities. 2. All required copies of plans and specifications for the project bid documents. 3. All necessary environmental documentation for the project. 4. Sample specifications for similar projects including City boilerplate. 5. Blank mylar with City title block. 6. Standard City title sheet. 7. Pothole information, if needed and not provided by utility owners. 8. Pavement coring data and deflection testing. EXCLUSIONS Specifically excluded from the services to be performed under the provisions of this proposal are the following: 1. Any services related to right-of-way acquisition. 2. Modifications to the existing traffic signals (except preservation or replacement of damaged traffic loop detectors). 3. Landscape and irrigation plans. 4. Construction administration. 3 EXHIBIT 2 ,,< - - - - - - - - - - 0 ~ 0- .. n ~ r ~ ;! ~ ji i! = " ii II " " il II I' n 01 II ,,< - If -,- -,- -,- -,- -,- -,- ~~ ~f V> ~ 0- 1, II " Ii I ,I Ii H Ii " 11 II r ,.; Ii n u !j H ;; " jl :! " % ,I ;1 ~ jj I! ji !I jj II ~ II ); jj II :I '" ~ " " I! I' << ~ I jj ii Ii ;I '" on I, I~ ~ il " ~~ ii '" ~ N .H. i~ , ~ ~ ,.0 0- il ;, II if ir E II 'I II ii ~ " !i I! n 11 ~ ii il U Ii Ii d Ii '" .. Ii 'I ~ !! ij ii " .... ii = " '" ~ II Ii !i rn "- j! J d ii !! 11 II " n H " H ii , 1i w if Jl II !i ,'. J~ - - - - - - - Jj.. '0 '" 0- il :1 I! !, iI ii !i !I U " " ii ji :j " 'j ii " i! II !i ~ i n Ii Ii t! !i L! II !i II 11 II q .-.1 ~ l.i. ~ - - - - - - - - - .ll .:...., ,.0 0- = = , , E ,~ ,- , , , , , , , '" , , , , ,~ , ,... ~ ,. , % ,', 0- , .~ 0- , , ~ , << ~ , ~ '" , on ::; , , ~ , w ~ '" ,-, , ~ '" << % , = '" ~ . , = ~ = . w '" ~ '" = % on << ~ ~ ,~ = '" % ~ ,... z on ~ '" '" '" '" ,n :=' ~ '" ~ :=: ~ ~ w '" '" ~ ~ % W = << ~ ~ ,-" w = '" % ~ Z ,~ = z '.0 ,~ ~ V> << '" = ~ ,n .n z .~ ~ ~ on ~ = ~ c, "- ~ z :=: "- ~ = << '" ~ .", ~ '~ '" ~ = := -or ~ on "- '" ~ "- ~ ~ ~ % ,~ ~ <J> << ~ ~ ~ ~ .. = ~ ci> ~ ,~ ~ ~ ,n . ,~ ;:- z on ~- ~ "- = '" "- w ~ ~ ~ % ~ "- ~ ~ z ~ << E ~ = '" ~ ~ ~ C' ~ ~ w z ~ ~ << << ~ ~ on "- ~ := '" on ~ ,. ,. z ;:!; ~ ~ ~ = ~ << '" "- ,~ V> ~ ~ '" un = "- on on .~ un ~, ~, "- "- E .; '" "" '" ... '" WJ;e...... u == g.~ co 0 .;::) r_ ... ':.n 0- ..... '" .:::;. ~ ~ ~:; -" ~ ~ ,~ ~ ,~ ~ - ... .~ '" (Xl <2: :z ,=> ~ ~ Q Q ~ '" :z Ul ocJ:: :z: ,:;::I Z ~::t: o.:c:: ... ~ ~ '" ,::::, C> :z ~ ~ "" .:~ --0 .:.n 'n => J .:.0..:; n I % ... ~ ... ~ ~ ~ o '" .cr ~ .. o "' "- ,n ~ ~ '" "" ~ "" '" ~ ~ ~ '" '" ~ Q... ~ '" ... ~ '" :zOO '" Q ~ ~ ~ ,.x a: ~ CO '" '" ~ X ~ '" '" '" '" ~ , ~ ~ z z '" '" ~ '" ... ~ ~ "" - c::o 4: := ~ ."'j a- C>- , * * C>- ~ ~ c-.; .~ -'- .. e ~ c ~ ;$c:o~g~~ggOQ.::::.c>g ...c r- 0'-....... 1''') r"-l ..0 J:"o,I ..0 I"') c:c N..,......... o .:::;. Co .0 .:::> .:=> .0 .:::> .~ 0 ,0 0 .::> .., .., '" .... M '" '" '" "" ~ .., '" oo ~ ~ ~ ~~gg'::>O'::>O;$ ....... 1''';1 N -C .:-... ....... N... I'-? ..::::- Co .... '" ~ ~ ~~~_;g~~~ooo':::>~ ~ '" .0<--.1.:::>0.0000.0.0000 N en oco.::;:.o.:;::.oo.:=:-ooooo .... ~ .0 ,0 ,~ .0 .:::> '0 Co ... 0 .::> .:;::. .:;::. ~ 0:..... ~ o 0 .::;:. .::;:. ..,. 0 ..,. 0 .:::;. .::> .0 .::;:. .0 C'.... r.--I '" oooo...o_oc>o':~.:;::.c>o 0- .-..! ~'::::>CDOgO~':::;'O'::>O'::>O c:cc>_C>~~~ 0000':::>-0 ~ "" _0000_0_..,..::00000..0 C... '" ~ ;< r-.. c--l ............., <:'.. .."" ("'-I L-", N ,.............. r-.l r-... ~~~~O-~~~~O-O-O'-'2: o ...,.. ..., 0- 00 .;:> 0 .:::;. t-') 1"-.... ~ 1.1. 1.1") N':;::'c.:~~~~......:~ .....N C".... (""11.1"') 1'''' "'T ",,"........ 1''') _ 1/':11.1") It':I 0'-::>000-:::>0=.:;::'<::>00.:;::. ,~ L-"......... ('oj .-.... N ,~... C'" C'-l L"-.j........ N ,"", l....... 0- 0- o. 0- 0- 0- 0- 0- 0- 0- 0- 0- 0- r.") r.~, t.") """ -0 t.'") t.'") o. .:::;. 00 - t.") o:~.-::> N NN.:::>I-')....-.I.......:2: S~~~:;~8~S8~8:J6~8 ui "" ~ ~ > ~ '" '" ~ ~ ~ z .., ~ ~ ~ z O:z: rJ) '" ~ ~ Z 4 l-- LU .:.0 ::z a: x: ::z: =LU fflU) I:::> ....J :> .:.... u.J ::z: .:c; <:r 0 1- <:::I c::r :> .:c: a;: ".1: = u.J a... t-- E: t-- ':.J x: (f) ...-.J: ~ ~ ~ ~ ~ = cu ~ ~ > ~ ~ '" = % 2: '" - ~ ~ = .:x; t-- uJ eX u..J :lIL: ~ u.J ~ -.I uJ u.J Ln .:c: :>.:.:: ~~=:;g:t;; = - en ~ = ~ 'J LO lFl = ~ ~ ~ ~ ~ ~ ;:> ~ ,~ ~ o:L CL .......J "" .-, .....:! ::o!': ;-::=, ~~ ~ ~ "" z ~ ~ ~ '" ~ ~ oo ~ ~ ~ - .., ~ '" = C>- OO oo '" .... "" "" oo .... '" ,.-, '" .... .., c. oo ,~ = c-,~ '" "" ~ * ~ ~ ~ ~ .cr ~ := * * * * EXHIBIT 3 ~ "' ~ .. o .. ~ .. ,.:x; .:3 .c-:, g :3 ::; c> g ::5 gg ...., .-;::> -0'" ~~ ", ,'-I U"? .. ~ o u .. u ~ ~ o ~ .. ~ ~ '" ~ = 1.-1..1':':: u:::::r: l...U u.J UJ L.J L.J UJ % u.J a:: .::r z :-"-.1: %UJ UJu.J ~i:5~%~ ~~ UJ <:r -.I::::J a: t--.- X:.;.., <:X: en W r..J Z en ,~ u.J u.J I:.D ...... % :z u.J '"":) ~ u..:r a:: <I:: :;;> <:::I 0 J).::t;L.J u.Jx,:,:: a.:: a:: L.U cx: u.J -.I I ::::J .:.. Y.. C:I ~ t-- r..J C'. Ln II H o:l::,;:c,L.JCoUJ~r~:I: EXHIBIT 4 . .. P & D TECHNOLOGIES SCHEDULE OF FEES 30-Dec-91 I PRINCIPALS: I PRINCIPAL-IN-CHARGE $/HOUR $150 LABOR CHARGE RATES IENVIRONMENTAL : I PROJECT ENVIR. ANALYST SR. ENVIR. ANALYST/SPECIALIST ENVIR. ANALYST/SPECIALIST SR. RESEARCHER RESEARCHER IPROJ. MANAGERS: I SR PROJECT MANAGER $120 $/HOUR $100 $85 $75 $65 $55 ISNdfNESf{$: PROJECT ENGINEER SR. ENGINEER ENGINEER DESIGN ENGINEER SR. DESIGNER DESIGNER SR. DRAFTER/CADD OPER. DRAFTER/CADD OPER. ENGINEERING TECHNICIAN $100 $90 $80 $65 $80 $65 $65 $50 $40 ITRANSP. PLANNERS: 1 PROJECT TRANSP. PLANNER SR.TRANSP.PLANNER TRANSP. PLANNER TRANSP. SYSTEM ANALYST TRANSP. TECHNICIAN $100 $90 $70 $60 $40 IECONOMISTS : SR. ECONOMIST ECONOMIST ECONOMIC ANALYST $120 $95 $65 IPLANNERS: PROJECT PLANNER SA. PLANNER PLANNER SR. PLANNING TECHNICIAN PLANNING TECHNICIAN $100 $90 $80 $70 $45 I LANDSCAPE ARCHITECTS: PROJECT LAND. ARCHITECT SA. LAND. ARCHITECT LAND. ARCHITECT STAFF LAND. ARCHITECT $100 $90 $75 $60 IOTHER STAFF: WORDPROCESSING REPORT PREP./EDITING PROJECT CONTROL $55 $50 $55 I GRAPHICS: SR. GRAPHICS GRAPHICS $65 $50 REIMBURSABLE EXPENSES I HANDLING FEE * MILEAGE REPRODUCTION SINGLE SIDED REPRODUCTION TWO SIDED 15.00 % $0.25/MILE $0.05/COPY $0.07/COPY VISUAL SIMULATION /HOUR CADD/COMPUTER TIME /HOUR DELIVERIES /HOUR REPRODUCTION 11 X 17/COPY $25 $25 $30 $0.20 'INCLUDES REPORT PRINTING/REPRODUCTION. GRAPHIC AIDS. TRAVEL(AIRFARE.MEALS,ETC.), FEES BY GOVERNING BODIES, COMPUTER SERVICES, PHOTOGRAPHY. SUBCONTRACT SERVICES. POSTAGE, TELEPHONE/FAX AND DELIVERY. ACCOUNTS ARE DUE AND PAYABLE WITHIN 30 DA YS OF THE DATE OF THE INVOICE. PAST DUE ACCOUNTS WILL HAVE A FINANCE CHARGE OF 1.2596 PER MONTH COMPOUNDED. ALL RATES MA YBE SUBJECT TO CHANGE AT SUCH TIME AS ADJUSTMENTS ARE MADE AS A RESUL TOF AGREEMENTS, SALARY ADJUSTMENTS AND INCREASED BUSINESS EXPENSES. I RATES EFFECTIVE THRU: 12/31/92