Loading...
HomeMy WebLinkAbout1995-131 , 1 RESOLUTION NO. 95-131 6 SECTION 1. The Mayor of the City of San Bernardino is 7 hereby authorized and directed to execute, on behalf of said 8 City, an agreement with McDaniel Engineering Company for: 9 Independent Check of Bridge Calculations for Bridges along the 10 Orange Show Road Extension, a copy of which agreement is attached 11 hereto, marked Exhibit "A" and incorporated herein by reference 12 as fully as though set forth at length. 13 SECTION 2. The agreement shall not take effect until 14 fully signed and executed by both parties. The City shall not be 15 obligated hereunder unless and until the agreement is fully 16 executed and no oral agreement relating thereto shall be implied 17 or authorized. 18 SECTION 3. The authorization to execute the above- 19 referenced agreement is rescinded if the parties to the agreement 20 fail to execute it within ninety (90) days of the passage of this 21 resolution. 22 / / / / 23 / / / / 24 / / / / 25 / / / / 26 / / / / 27 / / / / 28 / / / / 3-15-95 /)~o::://::'! RESO: AUTHORIZING EXECUTION OF AGREEMENT WITH McDANIEL ENGINEERING COMPANY FOR INDEPENDENT CHECK OF BRIDGE CALCULATIONS. 1 I HEREBY CERTIFY that the foregoing resolution was duly 2 adopted by the Mayor and Common Council of the City of San 3 Bernardino at a 4 1st day of May 5 Council Members: 6 NEGRETE 7 CURLIN 8 HERNANDEZ 9 OBERHEL~1A1l 10 DEVLIN 11 POPE-LUDLAM 12 MILLER 13 14 15 16 17 18 19 20 21 The foregoing day of May regular meeting thereof, held on the , 1995, by the following vote, to-wit: AYES NAYS ABSTAIN ABSENT x x x x x x x 'i{adtJ MOAJu ~Rachel Clar~ity Clerk resolution ~ h&~~~~ed tf'J!P~ , 1995. Approved as to form and legal content: James F. Penman City Attorney 22 23 ~a.i 24 25 26 27 28 ,~~ . Tom Minor, Mayor Ci ty of San Bernardino - 2 - . ,... q,,/?>/ Exhibit RA- AGREEMENT FOR PROFESSIONAL SERVICES This AGREEMENT is made and entered into this 1st day of September , 1995, by and between the CITY OF SAN BERNARDINO, California, a municipal corporation, hereinafter referred to as the "CITY" and McDaniel Enqineerinq Company. Inc., a California corporation, hereinafter referred to as "Engineer." WIT N E SSE T H WHEREAS, City desires to obtain professional engineering services to prepare independent bridge calculations on the damage to the Central Ave Bridge and preliminary estimates for the repair; and to obtain a complete set of plans, specifications and estimate; and WHEREAS, in order to complete the bridge evaluation, calculation and documents, it is necessary to retain the professional services of a qualified engineering and consulting firm; and WHEREAS, Engineer is qualified to provide said professional services; and WHEREAS, San Bernardino city has elected to engage the services of Engineer upon the terms and conditions as hereinafter set forth. NOW, THEREFORE, it is mutually agreed, as follows: 1. SCOPE OF SERVICES Engineer shall perform those services as set forth below: Phase I - Provide a Field Investigation and Recommendations for repair of damaged portions, per letter dated 8/14/95. Phase 11- Provide Bridge Engineering Services consisting of a complete set of construction plans, specifications, and estimate ready to be advertised for bids, per the recommendations provided under Phase I. 2. TERM OF AGREEMENT The services of Engineer are to commence within five (5) days after the City has authorized work to start by issuance of a Notice to Proceed. The completion date is to be as soon as practical and will be adjusted by Engineer as the City authorizes the work. Any adjustments shall require City approval prior to commencement of performance of work requested by the City. This Agreement shall expire in 90 days unless extended by written agreement of the parties. . f ./ " .1/:, /'1' too' 3. STANDARD OF PERFORMANCE Engineer shall complete all work product and design in conform- enc with Standard Specifications for Public Works Construction (Green- book) the City of San Bernardino's Standard Drawings and the requirements of reasonable engineering design for bridges. 4. CHANGES/EXTRA SERVICES A. Performance of the work is made an obligation of Engineer under this Agreement, subject to any changes made subsequently upon mutual agreement of the parties. All such changes shall be incorporated by written amendments to this Agreement and include any increase or decrease in the amount of compensation due Engineer for the change in scope. Any change which has not been so incorporated shall not be binding on either party. B. No extra services shall be rendered by Engineer under this Agreement unless such extra services are authorized, in writing, by city prior to performance of such work. Authorized extra services shall be invoiced based on Engineer's written estimate for any additional services. 5. COMPENSATION A. The City shall reimburse the Engineer for actual costs (including labor costs, employee benefits, overhead, profit, other direct and indirect costs) incurred by the Engineer in performance of the work, in amounts not to exceed: Phase I $ 5,000.00 $18.500.00 Phase II Total $23,500.00 Actual costs shall not exceed the estimated wage rates and other costs contained in the standard rates, prepared by the Engineer, for service in effect during this contract and as attached hereto. B. Said compensation shall not be altered unless there is significant alteration in the scope, complexity or character of the work to be performed. Any such significant alteration shall be agreed upon in writing by city and Engineer before commencement of performance of such significant alteration by Engineer. Any adjustment of the permitted when the Engineer writing, that there has been, total cost establishes or is to be, of services will only be and City has agreed, in a significant change in: Page 2 ,~,.r ?..... 1. scope, complexity, or character of the services to be performed; 2 . Condi tions under which the work is required to be performed; and 3. Duration of work if the change from the time period speci- fied in the Agreement for Completion of the work warrants such adjustment. C. The Engineer is required to comply with all Federal, State and Local laws and ordinances applicable to the work. The Engineer is required to comply with prevailing wage rates in accordance with California Labor Code Section 1770. 6. PAYMENT BY CITY A. The billings for all services rendered pursuant to this Agreement shall be submitted monthly by Engineer to City and shall be paid by City within twenty (20) days after receipt of same, excepting any amounts disputed by city. Dispute over any invoiced amount shall be noticed to the Engineer within ten (10) days of billing and a meet and confer meeting for purposes of resolution of such dispute shall be initiated by the City within ten (10) days of notice of such dispute. Interest of 1-1/2 percent per month (but not exceeding the maximum rate allowable by law) will be payable on any amounts not in dispute and not paid within thirty (30) days of the billing date, payment thereafter to be applied first to accrued interest and then to the principal unpaid amount. On disputed amounts, interest shall accrue from thirty (30) days of the invoice date if the amount in dispute is resolved in favor of the Engineer. All tasks as specified in Exhibit "I" shall be completed prior to final payment. B. The parties hereto agree not to be bound by any requirement for arbitration of any dispute arising hereunder. Disputes shall be resolved by agreement of the parties, or upon the failure of such agreement, by direct application to the Courts. C. Should litigation be necessary to enforce any term or provision of this Agreement, or to collect any portion of the amount payable under this Agreement, then all litigation and collection expenses, witness fees, and court costs, and attorney's fees shall be paid to the prevailing party. 7. SUPERVISION AND ACCEPTANCE OF SERVICES A. The Director of Public Works of city, or his designee, shall have the right of general supervision over all work performed by Engineer and shall be City's agent with respect to obtaining Engineer's compliance hereunder. No payment for any services rendered under this Agreement shall be made without prior approval of the Director of Public Works or his designee. Page 3 , ,~., B. The Office of the Administrator may review and inspect the Engineer's activities during the progress of the program. 8. COMPLIANCE WITH CIVIL RIGHTS LAWS Engineer hereby certifies that it will not discriminate against any employee or appl icant for employment because of race, color, religion, sex, marital status or national origin. Engineer shall promote affirmative action in its hiring practices and employee policies for minorities and other designated classes in accordance with Federal, State and Local laws. Such action shall include, but not be limited to, the following: recruitment and recruitment advertising, employment, upgrading, and promotion. In addition, Engineer shall not exclude from participation under this Agreement any employee or applicant for employment on the basis of age, handicap, or religion in compliance with state and Federal laws. 9. TERMINATION OF AGREEMENT A. This agreement may be terminated by either party upon thirty (30) days' written notice in the event of substantial failure of the other party to perform in accordance with the terms of this Agreement. Each party shall have twenty (20) days following date of such notice within which to correct the substantial failure, giving rise to such notice. In the event of termination of this Agreement, City shall within thirty (30) days pay Engineer for all the fees, charges and services performed to City's satisfaction by Engineer, which finding of satisfaction shall not be unreasonably withheld. Engineer hereby covenants and agrees that upon termination of this Agreement for any reason, Engineer will preserve and make immediately available to City, or its designated representatives, maps, notes, correspondence, or records related to work paid for by the city and required for its timely completion, and to fully cooperate with city so that the work to be accomplished under this Agreement may continue within forty-five (45) days of termination. Any subsequent use of such incomplete documents shall be at the sole risk of the City, and the City agrees to hold harmless and indemnify Engineer from any claims, losses, costs, including attorney's fees and liability arising out of such use. Engineer shall be compensated for such services in accordance with this agreement. B. This agreement may be terminated for the convenience of the city upon thirty (30) days written notice to Engineer. Upon such notice, Engineer shall provide work product to City, and City shall compensate Engineer in the manner set forth above. C. Following the effective date of termination of Agreement pursuant to this section, the Agreement shall continue all obligations arising from such termination are satisfied. this until Page 4 1';: /'~I ,- 10. CONTINGENCIES In the event that, due to causes beyond the control of and without the fault or negligence of Engineer, Engineer fails to meet any of its obligations under this Agreement, and such failure shall not constitute a default in performance, the City may grant to Engineer such extensions of time and make other arrangements or additions, excepting any increase in payment, as may be reasonable under the circumstances. Increases in payment shall be made only under the "changes" provision of this Agreement. Engineer shall notify City within three (3) days in writing when it becomes aware of any event or circumstance for which it claims or may claim an extension. 11. INDEPENDENT CONTRACTOR Engineer shall act as an independent contractor in the perfor- mance of the services provided for under this Agreement. Engineer shall furnish such services in its own manner and in no respect shall it be considered an agent or employee of City. 12. ASSIGNMENT OR SUBCONTRACTING Neither this Agreement, nor any portion thereof, may be assigned by Engineer without the written consent of city. Any attempt by Engineer to assign or subcontract any performance of this Agreement without the written consent of the city shall be null and void and shall constitute a breach of this Agreement. All subcontracts exceeding $10,000, shall contain all provisions of this contract. 13. NOTICES All official notices relative to this Agreement shall be in writing and addressed to the following representatives of Engineer and city: ENGINEER CITY Mr. Jack L. Abcarius McDaniel Engineering Company, Inc 1535 S. "D" st. suite 120 San Bernardino, CA 92408 (909) 889-8113 Mr. Roger Hardgrave Director of Public Works/ City Engineer 300 North "D" Street San Bernardino, CA 92418 (909) 384-5025 Page 5 c::JJ~_/::'1 , ' 14. RESPONSIBILITIES OF PARTIES A. The Engineer may reasonably rely upon the accuracy of data. provided through the City or its agents without independent evaluation. B. The city shall pay all costs of inspection and permit fees. Charges not specifically covered by the terms of this Agreement shall be paid as agreed by the parties hereto at the time such costs arise;* but in no event shall the work to be performed hereunder cease as a consequence of any unforeseen charges unless by mutual written' agreement of City and Engineer. C. All tracings, survey notes, and other original documents are instruments of service and shall remain the property of Engineer except where by law, precedent, or agreement these documents become public property. All such documents or records shall be made accessible to City. Engineer shall maintain all records for inspection by the City, State, or their duly authorized representatives for a period of three (3) years after final payment. Engineer shall stamp and sign all specifications, estimates, plans and engineering data furnished, and, where appropriate, indicate registration number. 15. CONSTRUCTION COST ESTIMATES A. Any opinion of the construction cost prepared by Engineer represents his judgment as a design professional and is supplied for the general guidance of the City. Since Engineer has no control over the cost of labor and material, or over competitive bidding or market conditions, Engineer does not guarantee the accuracy of such opinions as compared to contractor bids or actual cost to the City. For this project, no independent check of the existing engineering estimate is required. 16. COVENANT AGAINST CONTINGENT FEE Engineer warrants that no person or selling agency has been employed or retained to solicit or secure this Agreement upon an agreement or understanding for a commission, percentage, brokerage, or contingent fee, excepting bona fide employees or bona fide established commercial or selling agencies maintained by the Engineer for the purpose of securing business. For breach or violation of this warranty, City shall have the right to terminate this Agreement in accordance with the clause permitting termination for cause and, at its sole discretion, to deduct from the Agreement price or consideration, or otherwise recover, the full amount of such commission, percentage, brokerage or contingent fee. Page 6 ,.-;;~r,-. i::"l ,. 17. HOLD HARMLESS CLAUSE A. Engineer hereby agrees to hold City, its elective, and appointive boards, officers, and employees, harmless from any liability for damage or claims for damage for personal injury including death, as well as from claims for property damage, which may arise from Eng- ineer's negligent acts, errors or omissions under this Agreement. B. Engineer shall indemnify, defend and hold free and harmless the City, its officers, and its employees from all claims, damages, costs, expenses, and liability, including, but not limited to, attor- ney's fees imposed upon them for any alleged infringement of patent rights or copyrights of any person or persons in consequence of the use by City, its officers, employees, agents, and other duly authorized representatives, of programs or processes supplied to city by Engineer under this Agreement. 18. INDEMNITY Engineer shall indemnify, defend and hold harmless city from and against any and all claims, demands, suits, actions, proceedings, judgments, losses, damages, injuries, penalties, costs, expenses (including attorney's fees), and liabilities, of, by, or with respect to third parties, which arise solely from Engineer's negligent performance of services under this Agreement. Engineer shall not be responsible for, and City shall indemnify, defend, and hold harmless Engineer from and against, any and all claims, demands, suits, actions, proceedings, judgments, losses, damages, injuries, penalties, costs, expenses (including attorney's fees) and liabilities of, by, or with respect to third parties, which arise solely from the city's negligence. with respect to any and all claims, demands, suits, actions, proceedings, judgments, losses, damages, injuries, penalties, costs, expenses (including attorney's fees) and liabilities of, by or with respect to third parties, which arise from the joint or concurrent negligence of Engineer and city, each party shall assume responsibility in proportion to the degree of its respective fault. 19. LIABILITY/INSURANCE A. Engineer's liability insurance for injury or damage to persons or property arising out of work for which legal liability may be found to rest upon Engineer other than for professional errors and omissions, shall be a minimum of $1,000,000. For any damage on account of any error, omission, or other professional negligence, Engineer's insurance shall be limited in a sum not to exceed $50,000 or Engineer's, fee, whichever is greater. B. The city will require the Engineer to provide Workers Compensation and comprehensive general liability insurance, including completed operations and contractual liability, with coverage suffi- cient to insure the Engineer's indemnity, as above required; and, such Page 7 ;r ~" insurance will include the city, the Engineer, their consultants, and each of their officers, agents and employees as additional insured. c. Engineer shall provide evidence of insurance in the form of a policy of insurance, in which the City is named as an additional named insured to the extent of the coverage required by this Agreement.t ~' 20. VALIDITY Should any provision herein be found or deemed to be invalid, this Agreement shall be construed as not containing such provision, and all other provisions which are otherwise lawful shall remain in full force and affect, and to this end the provisions of this Agreement are declared to be severable. 21. ENTIRE AGREEMENT This Agreement represents the entire and integrated agreement between the parties hereto and supersedes all prior and contemporaneous negotiations, representations, understandings, and agreements, whether written or oral, with respect to the subject matter thereof. This Agreement may be amended only by written instrument signed by both parties. IIII IIII Illl IIII IIII IIII IIII IIII IIII IIII IIII IIII IIII IIII IIII IIII IIII IIII IIII IIII IIII IIII IIII IIII IIII IIII IIII IIII Page 8 I AGREEMENT FOR: BRIDGE ENGINEERING SERVICES - CENTRAL AVE BRIDGE OVER WARM CREEK IN WITNESS WHEREOF, the parties hereto have caused this Agreement to be executed on the date written above by their duly authorized officers on their behalf. CITY OF SAN BERNARDINO BY: ,~Ult1';;;~ Shauna Clark, City Administrator McDANIEL ENGINEERING co., INC. By: ,.;.--V~~_-..-- Title: /"n~.~ coLt!'--~r Approved as to form and legal content: JAMES F. PENMAN City Attorney Page 9